# INDSIL HYDRO POWER & MANGANESE LTD v. STATE OF KERALA & ORS ETC

- **Citation:** [2019] 10 S.C.R. 647
- **Court:** Supreme Court of India
- **Decided:** 2019-07-30
- **Case number:** Civil Appeal Nos. 5943-5945 of 2019
- **Bench:** Dr. Dhananjaya Y Chandrachud, Indira Banerjee
- **Source:** https://unisonlegal.in/judgment/supreme-court-of-india/indsil-hydro-power-manganese-ltd-v-state-of-kerala-ors-etc-33001
- **Pages:** 22

## Headnote

Electricity : Pursuant to the policy decision of State
Government to allow the private agencies to set up hydel schemes,
the appellant was allowed to set up a Hydro Electric Project - MoU
was executed between the appellant and the KSEB - In terms of the
MoU, the appellant would operate the unit for 30 years from the
date of commissioning i.e. the date from which the power generated
by the appellant is fed into the KSEB grid - The MoU contemplated
that the transmission line required for transferring power from the
power house to the nearest grid sub-station upto a length of 4 Kms.
would be built by KSEB at the cost of the appellant and rest of the
transmission line was to be constructed by the KSEB at its own cost
- Delay in construction of transmission line led to institution of writ
petition by appellant before High Court wherein appellant claimed
power free of cost in terms of clause 9 and 10 of the agreement and
sought direction for expeditious construction of transmission line -
Pursuant to interim order, the Chief Electrical Inspector filed a report
to the effect that the installation of transformers was completed by
the appellant on 21 August 2000 but the sanction for energization
of 110 KV was not issued since the transmission lines were not ready
- High Court directed the State Government to deal with the
representations submitted by the appellant - Pursuant to order of
High Court, State Government passed order on 7 February 2001
opining inter alia that appellant was not entitled to the benefit of
the pre 1992 tariff concession till the completion of the transmission
line by KSEB; that the delay in the construction of the transmission
lines was not deliberate and was due to factors beyond control;
that the tariff concessions were provided to new industries which is
a distinct issue from captive power generation and hence the plea
 [2019] 10 S.C.R. 647
647
A
B
C
D
E
F
G
H
648
SUPREME COURT REPORTS
[2019] 10 S.C.R.
for a tariff concession could not be acceded to; and having regard
to the grievance of the appellant that it had been unable to evacuate
the power which it was positioned to generate for its captive unit,
KSEB ought to adhere to the time schedule which it had undertaken
to fulfill and complete the construction of the transmission lines by
28 February 2001 without fail - High Court dismissed the writ
petition eventually holding that there was no intentional delay in
construction of the transmission lines on the part of KSEB; that the
tariff concession was made available only to new industries; and
that the agreement between the parties did not disclose any specified
time limit for the provision of transmission lines - On appeal, held:
The agreement stipulated that the date of commissioning would be
construed as the date from which the power generated by the units
set up by the appellant was fed into KSEB grid - Though the contract
did not specify the exact length of the transmission line, clause 9
made it clear that for a length of 4 kms, construction would be at
the cost and expense of the appellant while the balance would be
constructed by KSEB at its own cost - Clause 3 postulated that
commercial operations would begin within a period of 30 months -
Thus, the only reasonable construction of the contract would be
that the obligations which were to be performed by KSEB, namely,
the construction of the transmission line must necessarily be
completed within the same period - Otherwise imposing an
obligation upon the appellant to commence commercial operations
within 30 months would have no meaning - Therefore, High Court
was not correct in holding that the contract did not stipulate any
timelines for the completion of the work of constructing the
transmission line - Clause 12 of the agreement contemplated a
situation where the KSEB grid is not in a position to absorb the
energy generated from the project for any reason including the
breakdown of transmission lines or any other reason beyond the
control of K

## Text

_Characters 0–39,749 of 51,288. This is a partial read: ask again with offset=39749 for what follows._

A
B
C
D
E
F
G
H
647
INDSIL HYDRO POWER & MANGANESE LTD.
v.
STATE OF KERALA & ORS ETC.
(Civil Appeal Nos. 5943-5945 of 2019)
JULY 30, 2019
[DR. DHANANJAYA Y CHANDRACHUD AND
INDIRA BANERJEE, JJ.]
Electricity : Pursuant to the policy decision of State
Government to allow the private agencies to set up hydel schemes,
the appellant was allowed to set up a Hydro Electric Project - MoU
was executed between the appellant and the KSEB - In terms of the
MoU, the appellant would operate the unit for 30 years from the
date of commissioning i.e. the date from which the power generated
by the appellant is fed into the KSEB grid - The MoU contemplated
that the transmission line required for transferring power from the
power house to the nearest grid sub-station upto a length of 4 Kms.
would be built by KSEB at the cost of the appellant and rest of the
transmission line was to be constructed by the KSEB at its own cost
- Delay in construction of transmission line led to institution of writ
petition by appellant before High Court wherein appellant claimed
power free of cost in terms of clause 9 and 10 of the agreement and
sought direction for expeditious construction of transmission line -
Pursuant to interim order, the Chief Electrical Inspector filed a report
to the effect that the installation of transformers was completed by
the appellant on 21 August 2000 but the sanction for energization
of 110 KV was not issued since the transmission lines were not ready
- High Court directed the State Government to deal with the
representations submitted by the appellant - Pursuant to order of
High Court, State Government passed order on 7 February 2001
opining inter alia that appellant was not entitled to the benefit of
the pre 1992 tariff concession till the completion of the transmission
line by KSEB; that the delay in the construction of the transmission
lines was not deliberate and was due to factors beyond control;
that the tariff concessions were provided to new industries which is
a distinct issue from captive power generation and hence the plea
 [2019] 10 S.C.R. 647
647
A
B
C
D
E
F
G
H
648
SUPREME COURT REPORTS
[2019] 10 S.C.R.
for a tariff concession could not be acceded to; and having regard
to the grievance of the appellant that it had been unable to evacuate
the power which it was positioned to generate for its captive unit,
KSEB ought to adhere to the time schedule which it had undertaken
to fulfill and complete the construction of the transmission lines by
28 February 2001 without fail - High Court dismissed the writ
petition eventually holding that there was no intentional delay in
construction of the transmission lines on the part of KSEB; that the
tariff concession was made available only to new industries; and
that the agreement between the parties did not disclose any specified
time limit for the provision of transmission lines - On appeal, held:
The agreement stipulated that the date of commissioning would be
construed as the date from which the power generated by the units
set up by the appellant was fed into KSEB grid - Though the contract
did not specify the exact length of the transmission line, clause 9
made it clear that for a length of 4 kms, construction would be at
the cost and expense of the appellant while the balance would be
constructed by KSEB at its own cost - Clause 3 postulated that
commercial operations would begin within a period of 30 months -
Thus, the only reasonable construction of the contract would be
that the obligations which were to be performed by KSEB, namely,
the construction of the transmission line must necessarily be
completed within the same period - Otherwise imposing an
obligation upon the appellant to commence commercial operations
within 30 months would have no meaning - Therefore, High Court
was not correct in holding that the contract did not stipulate any
timelines for the completion of the work of constructing the
transmission line - Clause 12 of the agreement contemplated a
situation where the KSEB grid is not in a position to absorb the
energy generated from the project for any reason including the
breakdown of transmission lines or any other reason beyond the
control of KSEB - In that event, clause 12 provided the generation
from the project to be restricted to the extent of generation for captive
consumption as directed by KSEB - These provisions indicated that
the contract was not entirely silent in regard to a situation involving
the inability of KSEB's grid to absorb the energy generated from
the project for any reason - The report of the Chief Electrical
inspector made it clear that it was as a result of the delay which
took place in the construction of the transmission line that the actual
A
B
C
D
E
F
G
H
649
injection of power into the grid could not take place - This clearly
showed that the appellant had duly fulfilled its obligation of setting
up Phase I and Phase II of its units and the only reason why it was
unable to inject power into the grid was because the setting up of
the transmission lines by KSEB could not take place - Thus, the
basis on which State Government took a decision on 7 February
2001 and High Court affirmed it by its impugned judgment would
need to be re-visited - Appellant was not entitled to the grant of
deemed generation status as a matter of right - Similarly, the
concessional power tariff applicable for a period of five years from
1994 to 1999 was extended until 20 August 2000 - This is
undoubtedly a matter of policy and the High Court was justified in
coming to the conclusion that it was not open to the Court to foist a
particular measure of policy on the State - State Government to
reassess the matter in proper perspective within the available
framework of law and its own policy.
Administrative Law: Contractual matters - Judicial review -
Scope of interference - Held: It is now a settled principle of law
that the exercise of writ jurisdiction under Art.226 is not excluded
in matters pertaining to contract - The States and its agencies are
duty bound to act in a manner which is fair and transparent - They
cannot act arbitrarily in dealings with private parties - This must
particularly be the governing principle where the State as a measure
of encouraging industrialisation invites the participation of private
industries to respond to the policy initiative of the State - Electricity.
Deeds and documents: Interpretation of commercial documents
- In construing a commercial document, the contract must be read
and understood in its entirety so as to attribute to it a business
meaning which was within the understanding of the contracting
parties - Electricity.
Disposing of the appeals, the Court
HELD: 1. In announcing the policy initiative on 7 December
1990, the State Government intended to encourage the setting
up of hydel power projects by private agencies and hence, a slew
of concessions came to be provided. The agreement that was
entered into between the appellant and the KSEB is undoubtedly
a matter in the contractual arena. It is now a settled principle of
law that the exercise of writ jurisdiction under Article 226 is not
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA
A
B
C
D
E
F
G
H
650
SUPREME COURT REPORTS
[2019] 10 S.C.R.
excluded in matters pertaining to contract. The States and its
agencies are duty bound to act in a manner which is fair and
transparent. [Para 33] [664-E-F]
2. In the instant case, under its agreement with KSEB, the
appellant assumed the obligation to set up Phases I and II of a
hydel project with a capacity of 21 MW and to operate the project
for a period of 30 years. After the expiry of 30 years, the project
would be handed over to the State free of cost. The agreement
stipulated that the date of commissioning would be construed as
the date from which the power generated by the units set up by
the appellant was fed into KSEB grid. Under clause 3 of the
agreement, the appellant was to furnish within three months a
programme for construction and installation towards the
completion of the project. Commercial operation was to be
achieved within a period of 30 months from that date. Under
clause 9 of the contract, KSEB assumed the obligation to set up
the transmission line. Though the contract did not specify the
exact length of the transmission line, clause 9 made it clear that
for a length of 4 kms, construction would be at the cost and
expense of the appellant while the balance would be constructed
by KSEB at its own cost. While a superficial reading of clause 9
alone is liable to lead to the interpretation that no time was fixed
for the completion of the transmission lines, this would not be a
correct reading of the contract. In construing a commercial
document, the contract must be read and understood in its
entirety so as to attribute to it a business meaning which was
within the understanding of the contracting parties. [Paras 3435] [664-G; 665-A-D]
3. Clause 3 postulated that commercial operations would
begin within a period of 30 months. The only reasonable
construction of the contract would be that the obligations which
were to be performed by KSEB, namely, the construction of the
transmission line must necessarily be completed within the same
period. Otherwise imposing an obligation upon the appellant to
commence commercial operations within 30 months would have
no meaning. This would result in a specific term of the contract
being rendered redundant which the Court must as a principle of
A
B
C
D
E
F
G
H
651
interpretation seek to avoid. Hence, the High Court was not
correct in coming to the conclusion that the contract did not
stipulate any timelines for the completion of the work of
constructing the transmission line. Such a requirement was
implicit in clause 3 of the agreement and clause 9 must necessarily
be read in that context. [Para 36] [665-E-H]
4. The submission which has been urged on behalf of KSEB
principally relies on the concessions which have been provided
to the appellant in regard to the tariff which is applicable to its
industrial unit. These concessions were available to all new
industries to whom a concessional tariff was provided over a period
of five years from 1994 to 1999. These concessions were
independent of and would not therefore disentitle the appellant
to the benefit of the agreement that was entered into with KSEB
on 30 December 1994. The grant of a concessional tariff is a
matter of policy to encourage new industries to set up operations
in the State. Clause 10 of the agreement stipulated that the energy
drawn from the hydel units - Phase I and Phase II - would be
delivered free of cost to the appellant less an amount of 12%
towards wheeling charges and transmission losses. Alternatively,
it would be banked by KSEB, if the appellant so desired. KSEB
would collect 1% of the energy so banked as its commission.
[Paras 37-39] [666-A-D]
5. Clause 12 of the agreement contemplates a situation
where the KSEB grid is not in a position to absorb the energy
generated from the project for any reason including the breakdown
of transmission lines or any other reason beyond the control of
KSEB. In that event, clause 12 provides that the generation from
the project will have to be restricted to the extent of generation
for captive consumption as directed by KSEB. These provisions
indicate that the contract is not entirely silent in regard to a
situation involving the inability of KSEB's grid to absorb
the energy generated from the project for any reason
including a reason which is beyond the control of KSEB.
[Para 40] [666-E-G]
6. The report of the Chief Electrical inspector makes it
clear that it was as a result of the delay which took place in the
construction of the transmission line that the actual injection of
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA
A
B
C
D
E
F
G
H
652
SUPREME COURT REPORTS
[2019] 10 S.C.R.
power into the grid could not take place. The order of the State
Government dated 7 February 2001 shows that there was no
deliberate act or default on the part of KSEB. Indeed, it has not
been seriously disputed that at the material time, there were
agitations on the part of the farmers and certain other
circumstances which caused delay in the construction of the
transmission lines. However as significant as these reasons are,
it should not lead to a situation where a private investor who has
acted upon the policy of the State Government being left in the
lurch as a result of supervening circumstances which have
resulted in the power not being evacuated into the grid due to
the non-commissioning of the transmission lines at the material
time by KSEB. It is imperative that contractual obligations
entered into by the State have legal sanctity. A legal regime where
the sanctity of contracts is respected and commercial contracts
are enforced is essential to the maintenance of the rule of law.
Trade and commerce can be freely conducted in a stable legal
order which provides remedies for enforcement. [Paras 42, 43]
[667-B-F]
7. Though in the order of the State Government dated 7
February 2001, it was envisaged that the transmission lines would
be constructed and completed by 28 February 2001, there was a
further delay of approximately three months even thereafter as a
result of which the evacuation of power could commence only
with effect from 1 June 2001. On the basis of the factual data
which has emerged from the record, on which there is no dispute,
the basis on which the State Government took a decision on 7
February 2001 and the High Court affirmed it by its impugned
judgment would need to be re-visited. The appellant was not
entitled to the grant of deemed generation status as a matter of
right. Similarly, the concessional power tariff which is applicable
for a period of five years from 1994 to 1999 was extended until
20 August 2000. This is undoubtedly a matter of policy and the
High Court was justified in coming to the conclusion that it is not
open to the Court to foist a particular measure of policy on the
State. In what manner the State should remedy the grievance of
the private investor is something which should be duly considered
by the State Government within the available framework of law
and its own policy. [Paras 44, 45] [667-G-H; 668-A-C]
A
B
C
D
E
F
G
H
653
Shrilekha Vidyarthi (Kumari) v. State of U.P. (1991) 1
SCC 212 : [1990] 1 Suppl. SCR 625 ; ABL International
Ltd. v. Export Credit Guarantee Corpn. of India Ltd.
(2004) 3 SCC 553 ; Noble Resources Ltd. v. State of
Orissa (2006) 10 SCC 236 : [2006] 6 Suppl. SCR 53
- referred to.
Case Law Reference
[1990] 1 Suppl. SCR 625
referred to
Para 33
(2004) 3 SCC 553
referred to
Para 33
[2006] 6 Suppl. SCR 53
referred to
Para 33
CIVIL APPELLATE JURISDICTION : Civil Appeal Nos. 59435945 of 2019.
From the Judgment and Order dated 21.08.2015 of the High
Court of Kerala at Ernakulam in O.P. Nos. 6030 of 2001, 25360 of 2000
and W.P.(C) No. 20393 of 2003.
V. Giri, Joseph Kodianthara, Sr Advs., Amit, R. Gopalakrishnan,
Advs. for the Appellant.
C. K. Sasi, Nayantara Roy, Abdulla Naseeh V. J., P. V. Dinesh,
Ms Sindhu T. P., Mukund P. Unny, R. S. Lakshman, Bineesh K., Ashwini
Kumar Singh, Ms. Bina Madhavan, Ms. Anthony Elizabeth,
Ms. Akanksha Mehra (for M/s. Lawyer S. Knit & Co.), Advs. for the
Respondents.
The Judgment of the Court was delivered by
DR. DHANANJAYA Y CHANDRACHUD, J.
1. Leave granted.
2. These appeals arise from the judgment of a Division Bench of
the High Court of Kerala dated 21 August 2015. The High Court has
dismissed the writ proceedings instituted by the appellant under Article
226 of the Constitution of India.
3. On 7 December 1990, the State of Kerala issued G.O (Ms)
No. 23/90/PD by which private entities were permitted to construct and
operate Hydel Power Projects for the generation of power, subject to
certain conditions. These conditions, broadly speaking were:
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA
A
B
C
D
E
F
G
H
654
SUPREME COURT REPORTS
[2019] 10 S.C.R.
"
The Private Agencies would be allowed to set up sanctioned
hydel schemes at their own cost.
Where the power scheme is located in an area owned by the
Respondents, the land would be leased for a period of 30 years
from the date of commissioning of the same, after which the
land with all structures would vest in the Government free
from all encumbrances.
The transmission line required for transferring power from the
captive plant of the agency to the nearest grid sub-station would
be built at the cost of the agency by the KSEB and after
construction it would be transferred to the KSEB without any
compensation.
The captive plant energy fed into the KSEB grid - 12%
wheeling charges loss would be delivered free of cost to the
agency at their H.T. Terminals.
The percentage of 12% for Transmission & Distribution losses,
wheeling charges, etc. will be liable for review by Board during
revisions of tariff rates periodically.
Before implementation of the Scheme, an agreement setting
forth all the above aspects and such other conditions as found
necessary would be entered into between the agency and the
KSEB."
4. On 12 March 1992, the State government issued G.O (Ms) No.
5/92/PD by which the earlier Government Order was supplemented in
terms of the following conditions:
"
The power generated by the agencies could be utilized by them
in their own factories/business premises anywhere in the State
or could be sold to the KSEB.
For each project, the rate of purchase of electricity generated
will be notional ensuring a minimum rate of return as prescribed
by the Government."
A
B
C
D
E
F
G
H
655
5. The appellant is an EHT consumer with a contract demand of
14000 KVA. It has a power intensive unit for the manufacture of Ferro
Alloys which was energized on 12 August 1994. The appellant
commenced commercial production on 1 October 1994.
6. On 6 February 1992, the Government of Kerala provided
incentives to new industrial units by providing an exemption for five
years from the payment of enhanced tariff of electricity from 1 January
1992. This was made available to manufacturing units which commenced
commercial production on or before 31 December 1996. The pre-1992
tariff concession was allowed to the appellant for the period from 1
October 1994 to 30 September 1999. Pursuant to a policy decision of
the State Government, the appellant was also granted an extension of
the pre-1992 tariff for a further period commencing from 1 October
1999 until 20 August 2000. From 21 August 2000, the appellant is being
billed under the prevailing tariff. The pre-1992 tariff was at the rate of
Rs 0.42 per unit as against the cost of thermal power purchased by the
Kerala State Electricity Board which at the material time was Rs 3.30
per unit.
7. In pursuance of the policy decision of the State Government to
allow private agencies to set up hydel schemes, the appellant was allowed
to set up a Hydro Electric Project (Kuthungal Phase I & II) at Kuthungal,
Idukki District with a capacity of 21 MW as a captive power project in
terms of the Government Order dated 7 December 1990. The allotment
of the hydel project was confirmed in favour of the appellant in June and
July 1992. An MoU was executed between the appellant and KSEB in
pursuance of which the appellant was to set up a hydel project at
Kuthungal in Idukki District.
Some of the relevant terms of the agreement contemplated that:
"'Commercial Operation' i.e. the date on which power
generated by the Petitioner is fed into the KSEB Grid, was to
be achieved within 30 months from date of execution of the
agreement. A penalty would be levied if the Company was
not able to adhere to the above timeline.
If the Petitioner was not able to adhere to the agreed schedule,
for reasons beyond its control, the KSEB may consider the
request of the company for a revised schedule.
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA [DR. DHANANJAYA Y CHANDRACHUD, J.]
A
B
C
D
E
F
G
H
656
SUPREME COURT REPORTS
[2019] 10 S.C.R.
If the Petitioner is unable to complete the project or after
completion is unable to operate the project as per the schedule,
the KSEB shall have the right to take over.
The KSEB would build 4 kms of the transmission line required
for transferring power from the power house to the nearest
grid/substation at the cost of the Petitioner. The balance would
be constructed by the KSEB at its own cost as a promotional
measure.
The power generated - 12.0% (Wheeling & Transmission
Losses) would be available/delivered to the Petitioner at the
EHT Terminals at the point of supply in its installations.
If the KSEB grid was not in a position to absorb the energy
generated from the project for any reason beyond the control
of the KSEB, the generation from the project would be
restricted to the extent of generation for captive consumption
as directed by the KSEB.
In case of any dispute/difference between the parties, the
matter would be referred to the State Govt. and their decision
would be final and binding between the parties."
8. The agreement contemplated that the appellant as the project
agency would operate the unit for a period of 30 years from the date of
commissioning. The date of commissioning was defined to mean the
date from which the power generated by the appellant is fed into the
KSEB grid.
9. Clause 3 of the agreement stipulated that the appellant would,
upon the execution of the agreement, submit a programme of construction
and installation so that commercial operation is achieved within a period
of 30 months. The agreement contemplated that the transmission line
required for transferring power from the power house to the nearest
grid sub-station or location as suggested by KSEB, upto a length of 4
kms, would be built by KSEB at the cost of the appellant. The rest of the
transmission line was to be constructed by KSEB at its own cost.
10. Clauses 3 and 9 insofar they are material, are extracted below:
"3. The KSEB is entitled to check up, whenever it deems
necessary to see whether the conditions stipulated - "in respect
A
B
C
D
E
F
G
H
657
of installation, operation and maintenance are being adhered to by
the company. The company will furnish, within three months of
signing the Agreement, a programme of construction and
installation to the effect of completing the project in such a manner
that the commercial operation (the term, "commercial operation"
in this context indicates the date on which the power generated
by the company is fed into the KSEB grid) of the project is achieved
within 30 (thirty) months from that date..."
*****
*****
*****
*****
9. The transmission line required for transferring power from the
power house to the nearest grid, substation and/or other locations
as suggested by the KSEB upto a length of 4 (four) km shall, be
built by the KSEB at the company, as a deposit work and the
balance constructed by the KSEB at its cost as a promotional
measure for encouraging the private entrepreneurs for the
company by KSEB it shall be transferred to the KSEB without
any compensation. Land required for construction of such
transmission line will be considered as part of land required for
the project as per conditions as elaborated under clause (6) above
and the metering equipment as per the specifications of KSEB
shall be provided by the company at their cost at a point in the
generating station as approved by the KSEB and handed over to
the KSEB along with transmission line, without any compensation."
11. Clause 10 of the agreement contemplated that the energy
from the hydel units set up by the appellant and fed into the KSEB grid
less 12% towards wheeling charges and transmission losses would be
delivered free of cost to the appellant.
12. Clause 12 makes the following provision for a situation where
the grid of KSEB was not in a position to absorb the energy generated
from the project:
"12. If the KSEB grid is not in a position to absorb the energy
generated from the project for any reason such as high level of
storage in reservoirs, breakdown of transmission lines and/or other
reasons beyond the control of KSEB, the generation from the
project will have to be restricted to the extent of generation for
captive consumption as directed by KSEB. The schedule of power
generation from the project shall be as directed by the KSEB."
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA [DR. DHANANJAYA Y CHANDRACHUD, J.]
A
B
C
D
E
F
G
H
658
SUPREME COURT REPORTS
[2019] 10 S.C.R.
13. Clause 25 of the agreement envisaged that any dispute or
difference between the parties would be referred to the Government of
Kerala whose decision would be final and binding.
14. On 25 July 1998, the Chief Engineer of KSEB called upon the
appellant to deposit 2.13 crores for the construction of 4 km of the
transmission line in pursuance of clause 9 of the agreement. The amount
was deposited by the appellant on 5 October 1998. A further demand of
Rs 20,55,075 /- made on 5 May 1999 was also fulfilled.
15. The case of the appellant is that civil construction work was
completed and one of the three generators was commissioned and
synchronised with the grid on 15 May 2000. There was a delay in the
setting up of the transmission lines without which it was not possible for
the hydel unit to inject power into the KSEB grid. On 20 May 2000 and
30 June 2000, the appellant addressed representations in regard to the
delay. According to the appellant, on 21 August 2000, the remaining two
generators of the project were also commissioned and a certificate was
issued by the Chief Electrical Inspector of the Government of Kerala.
16. The delay in the construction of the transmission line led to
the institution by the appellant of a writ petition under Article 226 of the
Constitution of India before the Kerala High Court. The reliefs which
the appellant sought were in the following terms:
"a. Declare that the petitioner is entitled to consume power free
of cost at its plant at Palakkad namely Sun Metal and Alloy Limited
at Kanjikode in Palakkad and Indsil Electrosmelts Ltd. at Pallatheri
in accordance with clause 9 of Exhibit P2 order and clause 10 of
Exhibit P6 agreement calculated on the basis of the possible
consumption as mentioned by the Electricity Board in Exhibit P38
Budget proposal until such time as the Board lays the transmission
line and is ready to evacuate the power actually generated from
the Kuthungal Hydro Electric project in Kuthungal Idukki District.
b. Issue a writ in the nature of mandamus commanding second
respondent to take expeditious steps to see that the transmission
line required for transmission of power from Kuthungal to
Neriaoiangalam is completed as early as possible.
c. Issue a writ in the nature of mandamus commanding
respondents 2 and 3 to refrain from collecting any amount from
A
B
C
D
E
F
G
H
659
the petitioner by way of electricity charges or related charges for
the power consumed by the petitioner and its associate in
accordance with clause 10 of Exhibit P6 agreement on the basis
of the possible power generation as mentioned in P38 Budget
until evacuation of power generated in the project at 21 MW.
d. Issue a writ in the nature of mandamus commanding the first
respondent to take appropriate decision on Exhibit P.26, 35 and 36
representations by taking appropriate directions to the Board to
make available to the petitioner power in accordance with clause
9 of Exhibit P2 and Clause 10 of Exhibit P6 agreement."
17. In pursuance of an interim order passed by the High Court on
31 August 2000, the Chief Electrical Inspector of the Government of
Kerala filed a report on 14 September 2000. The Report, insofar as it is
material to these proceedings, states that the installation of transformers
was completed by the appellant on 21 August 2000 but the sanction for
energization of 110 KV was not issued since the transmission lines were
not ready. The Chief Electrical Inspector stated in his conclusions that
except for a pre-commissioning test and other minor work, installation
had been completed. What remained to be completed is the construction
of transmission lines by KSEB.
18. The conclusion in the report reads thus:
"Except for the pre-commissioning tests to be done prior to
energisation of the 110 KV lines, and minor works connected at
the time of pre-commissioning, the installation of the 3 bios of the
7 generators, 11 kv - switch gears 4 Nos. of the 11KV/110KV
step-up transformers, 500 KVA uxiliary transformer and the 110kv
yard is completed.
The 11 KV switch gears, transformers and the 110 KV yard are
completed and ready for evacuation of power generated
simultaneously by the 3 Nos. of 7MW generators installed at
Kuthungal only the 110 KV transmission lines are to be connected
which is now incomplete. The name plate details of the generators,
step-up transformers and equipment with 110 KV yard are
enclosed for reference."
19. The High Court of Kerala, by an order dated 1 November
2000, directed the State Government to deal with the representations
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA [DR. DHANANJAYA Y CHANDRACHUD, J.]
A
B
C
D
E
F
G
H
660
SUPREME COURT REPORTS
[2019] 10 S.C.R.
submitted by the appellant in terms of the dispute resolution procedure
contained in clause 25 of the agreement. The State Government was to
decide whether there was any delay in the construction of the transmission
lines by KSEB and to determine the claim of the appellant for the grant
of concessions including a deemed generation status or an extension of
the pre 1992 concessional tariff.
20. Pursuant to the order of the High Court, an order was passed
by the State Government on 7 February 2001. The State opined that:
(i)
There was no penal provision in the agreement providing a
consequence for a delay in the completion of the construction
of the transmission lines by KSEB;
(ii) The appellant was not entitled to deemed generation status
since this was neither a concession provided in the agreement
nor was the concession available to an entity such as the
appellant which generated power for its own consumption;
(iii) The appellant was not entitled to the benefit of the pre 1992
tariff concession till the completion of the transmission line
by KSEB;
(iv) KSEB had not deliberately delayed the construction and the
delay in the construction of the transmission lines was due to
factors beyond its control including public agitation and the
inaccessibility of the terrain;
(v) Tariff concessions are provided to new industries which is a
distinct issue from captive power generation and hence the
plea for a tariff concession could not be acceded to; and
(vi) Having regard to the grievance of the appellant that it had
been unable to evacuate the power which it was positioned
to generate for its captive unit, KSEB ought to adhere to the
time schedule which it had undertaken to fulfill and complete
the construction of the transmission lines by 28 February 2001
without fail.
Accordingly, the State Government directed that:
(i)
The appellant shall continue to remit the pre-1992 tariff from
August 2000 to February 2001;
A
B
C
D
E
F
G
H
661
(ii) The difference between the billed and the concessional tariff
shall be remitted to KSEB in 48 equal monthly instalments;
and
(iii) The penalties shall be waived.
21. The Writ Petition filed before the High Court was eventually
adjudicated upon in the impugned order of the Division Bench dated 21
August 2015. The Division Bench held that though the appellant was
permitted to put up a captive power plant in terms of the agreement
dated 30 December 1994, the agreement did not contemplate a situation
where the transmission lines will not be ready for evacuation of power.
The High Court held that there was no intentional delay in the construction
of the transmission lines on the part of KSEB. On whether or not the
concession should be granted to the appellant, the State Government
had already passed an order on 7 February 2001 opining that the tariff
concession was made available only to new industries. This procedure,
according to the State Government, was not available to captive power
generation units. The High Court held that this view was not contrary to
the policy of the State Government. The High Court held that the
agreement between the parties did not disclose any specified time limit
for the provision of transmission lines. The High Court accordingly
dismissed the Writ Petition.
22. Assailing the judgment of the High Court, it has been urged on
behalf of the appellant by Mr V Giri, learned Senior Counsel that acting
in pursuance of the agreement dated 30 December 1994, the appellant
completed the entire construction of the two units of the hydel project.
Mr Giri urged that the High Court was not correct in proceeding on the
assumption that the agreement did not contain a time limit for the
construction of the transmission lines. In this context, it was submitted
that clause 3 of the agreement obligated the appellant to furnish a
programme of construction within three months of the execution of the
agreement in such a manner that commercial operation was achieved
within 30 months from that date. It was urged that the expression
"commercial operation" has been defined as the date on which power
generated by the appellant is fed into the KSEB grid. Mr Giri submitted
that these provisions contained in clause 3 of the agreement have to be
read in the context of clause 9 under which KSEB assumed the obligation
to set up four kilometers of the transmission line at the cost of the appellant
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA [DR. DHANANJAYA Y CHANDRACHUD, J.]
A
B
C
D
E
F
G
H
662
SUPREME COURT REPORTS
[2019] 10 S.C.R.
and the balance on its own cost. On this basis, it was submitted that it
was the obligation of KSEB to achieve the completion of the installation
of transmission lines within the period stipulated by the agreement for
the commencement of commercial operation since in the absence of the
transmission lines, commercial operation would not become possible.
23. Mr Giri submitted that clause 9 of the agreement casts an
obligation on KSEB to carry out construction of the transmission lines.
Hence, though clause 9 does not expressly provide for a period of
completion, it must be read in the context of clause 3 under which
commercial operations, with reference to the injection of power into the
power grid, were to commence within a period of 30 months.
Consequently, it is urged that the duty to complete the transmission lines
must necessarily be fulfilled within the period of 30 months stipulated for
commencement of commercial operation.
24. Mr Giri urged that the failure to complete the construction of
transmission lines had a direct bearing on the appellant. If the transmission
lines were constructed, the appellant would have been in a position to
utilise the power generated by the hydel unit for captive consumption.
Instead, the appellant had to purchase electrical power from KSEB and
to pay for the purchase.
25. In this backdrop, it was submitted that the High Court was not
justified in coming to the conclusion that no period was stipulated for the
completion of transmission lines. Moreover, it was submitted that the
finding that the appellant would not be entitled to an extension of the
concessional tariff or deemed generation status would not solve the issue.
The appellant has to be compensated for the situation which has been
caused by the default of KSEB.
26. Mr Giri submitted that even after the State Government passed
an order on 7 February 2001, it is a matter of record that the transmission
lines were not completed by the date envisaged i.e. 28 February 2001.
As a result, evacuation of power could commence only with effect from
1 June 2001.
27. It has been urged that as a result of the demand for interest on
the differential tariff, the appellant will face a serious financial problem.
Mr Giri urged that though the appellant had not taken recourse to the
remedy of a civil suit for the recovery of damages, this was in view of
the ongoing relationship with the State Government and KSEB and it
A
B
C
D
E
F
G
H
663
would be appropriate if this Court were to direct that the State Government
should reconsider the matter afresh having regard to the grievances of
the appellant.
28. Mr Giri has also urged that clause 12 of the agreement
specifically contemplates a situation in which the KSEB grid is not in a
position to absorb the energy generated by the project for any reason, in
the event of which, it has been provided that the generation from the
project will be restricted to the extent of generation for captive
consumption as directed by KSEB.
29. On the other hand, it has been urged on behalf of the KSEB
by Mr P V Dinesh, learned counsel, that in the present case, the contract
was a commercial bargain between the appellant and KSEB. Learned
counsel submitted that in terms of the policy decision of the State of
Kerala, substantial tariff concessions have already been granted to the
appellant initially for a period of five years between 1 October 1994 and
30 September 1999 and thereafter by a further extension until 20 August
2000. Learned counsel submitted that whereas the pre 1992 tariff to
industries was at the rate of Rs 0.42 per unit, the cost of thermal power
purchased by KSEB is Rs 3.30 per unit. Hence, the appellant has paid
approximately 19.84 crores on account of the concessional tariff as
against an amount of Rs 51.32 crores towards energy charges alone
which would not have been possible had the normal rate of tariff been
applicable.
30. Moreover, it has been submitted that under the terms of the
agreement, KSEB undertook the obligation to fund a portion of the
transmission line over and above the distance of 4 kms which was
constructed at the cost of the appellant. For drawing the entire line of
16.77 kms, KSEB acquired a substantial tract of land which involved the
payment of compensation.
31. Mr Dinesh urged that as a result of the acquisition, there were
protests from the farmers due to which construction of the towers was
delayed. It was urged that in the order of the State Government dated 7
February 2001, a finding of fact was recorded to the effect that the
delay in the construction of the transmission lines was not occasioned by
any deliberate act on the part of KSEB. In this background, it has been
submitted that the appellant which had pressed its claim for grant of
deemed generation status and for a concessional tariff beyond 20 August
INDSIL HYDRO POWER & MANGANESE LTD. v. STATE OF
KERALA [DR. DHANANJAYA Y CHANDRACHUD, J.]
A
B
C
D
E
F
G
H
664
SUPREME COURT REPORTS
[2019] 10 S.C.R.
2000 is clearly not entitled to it in law. It was urged that the deemed
generation status cannot be allowed to the appellant which is a captive
power unit and, similarly, a concessional tariff is made available to new
industries which had already been availed of by the appellant. In this
view of the matter, it was urged that particularly in the background of
the fact that there was no deliberate act on the part of KSEB, the High
Court was not in error in dismissing the Writ Petition. It was urged that
the contract between the parties does not envisage any consequence
for a delay on the part of KSEB in erecting the transmission lines and
there is no specific provision in regard to the period within which the
transmission lines have to be set up.
32. Mr C K Sasi, learned counsel appearing on behalf of the State
of Kerala has placed reliance on the decision of the State Government
dated 7 February 2001 in support of the submission that relevant facts
have been taken into account.
33.