# K. L. SUNEJA & ANR v. DR. (MRS.) MANJEET KAUR MONGA (D) THROUGH HER LR & ANR

- **Citation:** [2023] 1 S.C.R. 1079
- **Court:** Supreme Court of India
- **Decided:** 2023-01-31
- **Case number:** Civil Appeal No.1401 of 2019
- **Bench:** M. R. Shah, S. Ravindra Bhat
- **Source:** https://unisonlegal.in/judgment/supreme-court-of-india/k-l-suneja-anr-v-dr-mrs-manjeet-kaur-monga-d-through-her-lr-anr-36975
- **Pages:** 20

## Headnote

Competition Act, 2002 - Monopolies and Restrictive Trade
Practices Act, 1969 - Code of Civil Procedure, 1908 - Payment of
interest on instalments towards allotment of a flat under construction
which was ultimately cancelled - Competition Appellate Tribunal
("COMPAT") held that complainant eligible for interest of 15% p.a.
from 1st May 2005 (when allotment was cancelled) to 7th May 2016
(when pay order was revalidated and cumulative instalment amount
was credited to the account of the complainant) - Builder argued
that complainant had filed 'original' pay order (issued in 2005)
before the COMPAT, and not intimated builder, hence amount was
deducted from builder's account in 2005 itself, and never credited
back - Impleaded Citibank averred that this contention was correct,
and submitted that the amount was credited to the 'Unclaimed Sundry
Amount' as instructed by Reserve Bank of India, where it remained
for the eleven years in question - Builder thus contended that it
had discharged its liability under Order XXI of the CPC.
Dismissing the complainant's appeal, the Court
HELD: 1.The provisions of Order XXI are applicable to
decrees of civil court. However, they embody a sound policy
principle, that if the amount is deposited, or paid to the decree
holder or person entitled to it, the person entitled to the amount
cannot later seek interest on it. This is a rule of prudence,
inasmuch as the debtor, or person required to pay or refund the
amount, is under an obligation to ensure that the amount payable
is placed at the disposal of the person entitled to receive it. Once
that is complete (in the form of payment, through different modes,
including tendering a Banker's Cheque, or Pay Order or Demand
Draft, all of which require the account holder / debtor to pay the
1079
 [2023] 1 S.C.R. 1079
A
B
C
D
E
F
G
H
1080
SUPREME COURT REPORTS
[2023] 1 S.C.R.
bank, which would then issue the instrument) the tender, or
'payment' is complete. [Para 31][1096-C-E]
2. In the present case, the complainant was aware that the
Pay Order had been tendered by the developer to her;
nevertheless she filed the original Pay Order with her complaint,
and did not seek any order from the MRTP Commission at the
relevant time. The pleadings in the complaint did not disclose
that the Pay Order was filed in the Commission, to enable the
developer to respond appropriately. In these circumstances, the
developer's argument that the rule embodied in Order XXI, Rule
4 CPC, is applicable, is merited. The developer cannot be
fastened with any legal liability to pay interest on the sum of 1
4,53,750/- after 30th April 2005. [Para 32][1096-E-G]
3.This court is also of the opinion that the complainant's
argument that on account of the omission of the developer, she
was wronged, and was thus entitled to receive interest, cannot
prevail. The records nowhere disclose any fault on the part of
the developer; on the other hand, the complainant did not take
steps to protect her interests. It has been held by this court, in
Sailen Krishna Majumdar v Malik Labhu Masih that in such cases,
even if equities are equal, the court should not intervene. [Para
33][1096-G-H; 1097-A]
Ghaziabad Development Authority vs. Ved Prakash
Agarwal C.A. No. 794/2001 : [2008] 8 SCR 676;
Hindustan Paper Corporation Ltd vs. Ananta
Bhattacharjee (2004) 6 SCC 213 : [2017] 6 SCR 453;
Gurpreet Singh vs. Union of India [2006] 8 SCC 457 :
[2006] 7 suppl. SCR 422; V. Kala Bharathi & Ors. vs
The Oriental Insurance Company Ltd. [2014] 5 SCC
577 : [2014] 5 SCR 1; Sailen Krishna Majumdar vs.
Malik Labhu Masih [1989] 1 SCR 817 - referred to.
Case Law Reference
[2008] 8 SCR 676
referred to
Para 6
[2017] 6 SCR 453
referred to
Para 17
[2006] 7 suppl. SCR 422
referred to
Para 17
A
B
C
D
E
F
G
H
1081
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR
[2014] 5 SCR 1
referred to
Para 20
[1989] 1 SCR 817
referred to
Para 33

## Text

_Characters 0–39,884 of 45,951. This is a partial read: ask again with offset=39884 for what follows._

A
B
C
D
E
F
G
H
1079
K. L. SUNEJA & ANR.
v.
DR. (MRS.) MANJEET KAUR MONGA (D) THROUGH HER LR
& ANR.
(Civil Appeal No(s). 1401 of 2019)
JANUARY 31, 2023
[M. R. SHAH AND S. RAVINDRA BHAT, JJ.]
Competition Act, 2002 - Monopolies and Restrictive Trade
Practices Act, 1969 - Code of Civil Procedure, 1908 - Payment of
interest on instalments towards allotment of a flat under construction
which was ultimately cancelled - Competition Appellate Tribunal
("COMPAT") held that complainant eligible for interest of 15% p.a.
from 1st May 2005 (when allotment was cancelled) to 7th May 2016
(when pay order was revalidated and cumulative instalment amount
was credited to the account of the complainant) - Builder argued
that complainant had filed 'original' pay order (issued in 2005)
before the COMPAT, and not intimated builder, hence amount was
deducted from builder's account in 2005 itself, and never credited
back - Impleaded Citibank averred that this contention was correct,
and submitted that the amount was credited to the 'Unclaimed Sundry
Amount' as instructed by Reserve Bank of India, where it remained
for the eleven years in question - Builder thus contended that it
had discharged its liability under Order XXI of the CPC.
Dismissing the complainant's appeal, the Court
HELD: 1.The provisions of Order XXI are applicable to
decrees of civil court. However, they embody a sound policy
principle, that if the amount is deposited, or paid to the decree
holder or person entitled to it, the person entitled to the amount
cannot later seek interest on it. This is a rule of prudence,
inasmuch as the debtor, or person required to pay or refund the
amount, is under an obligation to ensure that the amount payable
is placed at the disposal of the person entitled to receive it. Once
that is complete (in the form of payment, through different modes,
including tendering a Banker's Cheque, or Pay Order or Demand
Draft, all of which require the account holder / debtor to pay the
1079
 [2023] 1 S.C.R. 1079
A
B
C
D
E
F
G
H
1080
SUPREME COURT REPORTS
[2023] 1 S.C.R.
bank, which would then issue the instrument) the tender, or
'payment' is complete. [Para 31][1096-C-E]
2. In the present case, the complainant was aware that the
Pay Order had been tendered by the developer to her;
nevertheless she filed the original Pay Order with her complaint,
and did not seek any order from the MRTP Commission at the
relevant time. The pleadings in the complaint did not disclose
that the Pay Order was filed in the Commission, to enable the
developer to respond appropriately. In these circumstances, the
developer's argument that the rule embodied in Order XXI, Rule
4 CPC, is applicable, is merited. The developer cannot be
fastened with any legal liability to pay interest on the sum of 1
4,53,750/- after 30th April 2005. [Para 32][1096-E-G]
3.This court is also of the opinion that the complainant's
argument that on account of the omission of the developer, she
was wronged, and was thus entitled to receive interest, cannot
prevail. The records nowhere disclose any fault on the part of
the developer; on the other hand, the complainant did not take
steps to protect her interests. It has been held by this court, in
Sailen Krishna Majumdar v Malik Labhu Masih that in such cases,
even if equities are equal, the court should not intervene. [Para
33][1096-G-H; 1097-A]
Ghaziabad Development Authority vs. Ved Prakash
Agarwal C.A. No. 794/2001 : [2008] 8 SCR 676;
Hindustan Paper Corporation Ltd vs. Ananta
Bhattacharjee (2004) 6 SCC 213 : [2017] 6 SCR 453;
Gurpreet Singh vs. Union of India [2006] 8 SCC 457 :
[2006] 7 suppl. SCR 422; V. Kala Bharathi & Ors. vs
The Oriental Insurance Company Ltd. [2014] 5 SCC
577 : [2014] 5 SCR 1; Sailen Krishna Majumdar vs.
Malik Labhu Masih [1989] 1 SCR 817 - referred to.
Case Law Reference
[2008] 8 SCR 676
referred to
Para 6
[2017] 6 SCR 453
referred to
Para 17
[2006] 7 suppl. SCR 422
referred to
Para 17
A
B
C
D
E
F
G
H
1081
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR
[2014] 5 SCR 1
referred to
Para 20
[1989] 1 SCR 817
referred to
Para 33
CIVIL APPELLATE JURISDICTION : Civil Appeal No.1401
of 2019.
From the Judgment and Order dated 19.12.2018 of the National
Company Law Appellate Tribunal, New Delhi in Transfer Original Petition
(AT) (MRTP) No.5 of 2017.
With
Civil Appeal No.4530 of 2019
Nikhil Nayyar, Sr. Adv., Aditya Parolia, Piyush Singh, Akshay
Srivastava, Ms. Priyal Sarawagi, Naveen Hegde, Rajesh Kumar, Gaurav
Goel, Ms. Meenakshi Arora, Mohit Paul, Ms. Rangoli Seth, Ms. Suruchi
Suri, Chanchal Kumar Ganguli, Advs. for the appearing parties.
The Judgment of the Court was delivered by
S. RAVINDRA BHAT, J.
1. There are two appeals preferred against a common order of
the National Company Law Appellate Tribunal (hereinafter, "NCLAT"/
"Tribunal"). The first, by the original home buyer's legal representative
(hereinafter, "complainant") and the second by the builder / developer
(hereinafter, "developer").
2. In 1989, one Smt. Gursharan Kaur had applied for a flat in a
proposed group housing scheme called 'Siddharth Shila Apartments',
situated at Plot No. 24 in Vaishali Scheme, Ghaziabad, U.P. (hereinafter,
"Scheme"). After depositing three instalments towards the flat, she passed
away, and was succeeded by her daughter-in-law Dr (Mrs.) Manjeet
Kaur Monga, who deposited the fourth instalment. Thereafter, the
developer issued an allotment letter dated 21.05.1992, earmarking Flat
No. D-301 (3rd floor) with a super built- up area of 1375 sq. ft. in the
Scheme. Dr Manjeet Kaur Monga deposited two further instalments,
with the sixth instalment deposited in September 1993. Eight years later,
i.e., in December 2001, a demand notice for payment of the eighth and
ninth instalments was issued to the complainant. She resisted this notice,
as there was no intimation about the progress of work and delivery of
possession of flat to her. The developer however, issued a letter thereafter,
cancelling the allotment of the complainant's flat on 30th April 2005. The
A
B
C
D
E
F
G
H
1082
SUPREME COURT REPORTS
[2023] 1 S.C.R.
complainant had deposited seven instalments up to 4th October 1993
totalling ` 4,53,750/-. With the cancellation letter, the developer enclosed
a Pay Order dated 30th April 2005 for ` 4,53,750/- issued by Citibank
towards full refund of payments made by the complainant towards the
flat.
3. Aggrieved, the complainant through her lawyer, issued a notice
dated 7th September 2005 to the developer, stating that she was always
ready and willing to pay the instalments towards the flat, in tune with the
allotment letter, but the developer did not keep up its part of the bargain
regarding timeliness of delivery of possession and quality of construction.
The notice alleged that even 40% of the construction work had not been
completed till the seventh instalment, though the complainant had paid a
cumulative of ` 4,53,750/-. She demanded possession of the flat besides
claiming ` 25,00,000/- as compensation. With the notice, the complainant
returned the Pay Order of ` 4,53,750/-. She also sent a cheque of
` 1,00,000/- expressing willingness to pay the price of the flat. The
developer replied to the notice on 26th September 2005 denying the
allegations of delay in construction and accused the complainant of default
in payment of instalments. However, the developer did concede to slight
delay in completion of the project due to litigation with the Ghaziabad
Development Authority.
4. Dr. Manjeet Kaur Monga filed a complaint under Section 36
of the (then) Monopolies and Restrictive Trade Practices Act, 1969
(hereinafter, "MRTP Act") alleging unfair trade practice by the developer.
The complaint claimed physical possession of the flat or an alternative
flat of the same size and dimension. The complainant also applied under
Section 12A of the MRTP Act seeking to restrain the developer from
alienating flat D-301 in Siddharth Shila Apartments; she also filed C.A.
No. 39/2009 for award of compensation of ` 25,00,000/- under Section
12B of MRTP Act alleging to be a victim of unfair trade practice at the
hands of the developer. The MRTP Commission disposed off the
application filed under Section 12A of the MRTP Act restraining the
developer from creating third party interest with respect to the flat. The
developer also resisted the complaint and claimed that the complainant
was disentitled to any relief under the MRTP Act. It was further alleged
that the complainant had failed to deposit payments in accordance with
the plan in the allotment letter and that she had, in terms of her letter
dated 22nd May 2002, shown disinclination to take possession of the flat
A
B
C
D
E
F
G
H
1083
1 Dr (Mrs) Manjeet Kaur Monga vs. Mr K.L. Suneja, Civil Appeal No. 39/2009, dated
3rd August 2015.
2 Ghaziabad Development Authority vs. Ved Prakash Agarwal, C.A. No. 794/2001,
dated 14th May 2008.
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
by alleging breach of confidence on the part of the developer. The Notice
of Enquiry issued by the Commission was resisted on similar grounds.
5. Issues were framed for adjudication, which included whether
the developer had indulged in unfair trade practice, whether they were
prejudicial to the interest of the complainant and / or the public in general.
The MRTP Act was repealed by Section 66 of the Competition Act,
2002 which was brought into force w.e.f. 1st September 2009. Chapter
VIII-A introduced subsequently provided for establishment of an
Appellate Tribunal to hear appeals against orders passed by the
Competition Commission of India. The matters pending before MRTP
Commission were transferred to the (then) Competition Appellate Tribunal
(hereinafter, "COMPAT"). By order dated 29th July 2011, COMPAT
framed issues in the application filed under Section 12B of the MRTP
Act. The issues related to maintainability of the petition; whether unfair
trade practice had been proved; and if so, were they prejudicial to the
public; and also, if the complainant was entitled to any compensation.
6. Having regard to the evidence produced, COMPAT by its order1
concluded that the developer had falsely represented to the general public
(including the complainant) the time within which the project was to be
completed, i.e., three years, but did not complete the construction for
more than a decade. The COMPAT held the developer guilty of unfair
trade practice under Section 36-A (1) (i), (ii) & (ix) of the MRTP Act
and also ruled that the complainant was justified in not paying further
instalments and the developer committed illegality by cancelling the
allotment. Noticing the law laid down by this court in Ghaziabad
Development Authority vs. Ved Prakash Agarwal,2 COMPAT held
that it and its predecessor (MRTP Commission) could not assume the
powers of a civil court to grant relief akin to specific performance. Hence,
it declined the relief of delivery of possession of the flat. The COMPAT
however directed the developer to pay compound interest @ 15% per
annum to the legal representatives of the complainant with interest
calculated on each instalment from the date of its deposit till 30th April
2005, i.e., the date on which the allotment was cancelled. Besides, the
respondents were directed to pay the amount already invested by the
A
B
C
D
E
F
G
H
1084
SUPREME COURT REPORTS
[2023] 1 S.C.R.
complainant, i.e., ` 4,53,750/-, to the legal representatives of the
complainant.
7. COMPAT's order was challenged by both the complainant and
the developer through separate appeals before this court, which by its
order dated 18th July 2017,3 upheld the award of compensation to legal
representatives of the complainant in terms of the formula adopted by
the COMPAT. This court observed as follows:
"... Merely because a liquidated amount is not stipulated or
determined by the Tribunal, it cannot be said that it is not the
compensation. Once the interest, as ordered by the Tribunal,
is calculated that will be the amount of compensation referred
to under section 12-B of the Act."
8. This court also noticed the contentions of the developer that
when it had taken the Pay Order from Citibank on 30th April 2005, the
amount of ` 4,53,750/- covered by that instrument had been deducted
from its current account. It was not however received by the complainant
payee. The account holder / developer cancelled the Pay Order and
requested for re-credit of the amount; which was done by Citibank on
22nd June 2016. The court also noted the contention of Citibank that the
money deducted from current account of the developer in April 2005,
though not paid to the payee, was not enjoyed by the bank as the Pay
Order could have been presented at any moment. This court observed
that both these issues had not been considered by COMPAT, apparently
because these aspects were not addressed and Citibank was not a party
before the Tribunal. The court therefore disposed of the appeals by
remitting the matter to COMPAT with directions to implead Citibank as
an additional respondent. Additionally, the developer was directed to pay
the compensation worked at 15% compound interest up to 30th April
2005. The last issue which COMPAT was to consider on remand was
whether there should be any compensation and if so, what should be the
amount payable after 30th April 2005 and whether Citibank was liable to
pay any interest to the account holder.
Impugned Order of the NCLAT
9. After remand, the complainant impleaded Citibank as a
respondent. All respondents were allowed to file their respective affidavits
3 Dr (Mrs) Manjeet Kaur Monga (Thr. LH Karan Vir Singh Monga) vs. Mr K.L. Suneja,
Civil Appeal No. 5032 / 2017, dated 18th July 2017.
A
B
C
D
E
F
G
H
1085
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
in regard to payment of interest, if any, payable to the complainant from
1st May 2005 onwards. By the impugned order, NCLAT noticed the
facts leading to the order of this Court, including that the complaint was
filed in 2005 along with the original Pay Order, issued at the behest of
the developer by Citibank, which had been returned initially by the
complainant, but given back to the complainant. The NCLAT also
considered the affidavit and pleadings of the parties, including Citibank,
and noted that according to circulars, the amount of ` 4,53,750/- had
been deducted from the developer's account and that Citibank too did
not enjoy any interest on that amount, during pendency of the complaint
before COMPAT. The impugned order noted that the legal representatives
of the complainant did not get the refund of ` 4,53,750/- in terms of
order dated 3rd August 2015 by COMPAT as funds were credited back
to the account of the developer on 16th June 2016 and a fresh Pay Order
(bearing No. 262910) dated 16th June 2016 was issued by Citibank.
Ultimately that amount was made over to the complainant on 7th May
2016, in compliance with this court's orders dated 8th and 26th April 2016.
The NCLAT, by the impugned order, directed as follows:
"It is accordingly found that the direction of COMPAT in terms
of order dated 3rd August, 2015 in regard to payment of
Principal amount of Rs.4,53,750/- stood not complied with
till 7th May, 2016. In view of the same, the legal representatives
of the Complainant would be entitled to further compensation
in the form of compound interest @ 15% per annum on the
principal amount of Rs.4,53,750/- w.e.f. 1st May, 2005 till
7th May, 2016 further entitled to pendente lite and future
interest till realization of the accumulated arrears from
Respondents No. 1 and 2. (i.e., the developer)"
Contentions of the Complainant
10.The arguments on behalf of the complainant were common to
both appeals. It was urged that NCLAT fell into error as it failed to
appreciate that since the legal representatives of the complainant did not
get the refund of the amount of ` 4,53,750/- from the developer until 7th
May 2016, the interest on the said principal amount ought to run from 4th
October 1993 till the date of realization of the amount i.e. 7th May 2016.
11. It was argued that once the Tribunal found that the developer
was in the wrong - a determination that was upheld by this court, which
A
B
C
D
E
F
G
H
1086
SUPREME COURT REPORTS
[2023] 1 S.C.R.
held that the complainant was entitled to compensation, by way of
compound interest - that direction had to be taken to its logical end,
which meant that interest on the sum of ` 4,53,750/- was also payable
from the date it was deposited with the developer (in 1993) till the amount
was realized. This was the only restitutionary and equitable order, having
regard to all circumstances of the case.
12. It was submitted that the developer's argument that the amount
had been deducted from its account, and that it was not aware about the
filing of the original Pay Order, could not be countenanced. Learned
counsel highlighted, that moreover, the developer took full advantage of
the amounts deposited by the complainant, and after cancelling the
allotment, had immediately allotted the flat to another purchaser, for a
considerably higher sum of ` 21 lakhs. This fact was not disputed by
the developer. Therefore, the complainant could not be placed at a
disadvantage, because the amounts deposited and lying with the developer
had multiplied manifold. The developer had the advantage (twice over)
of obtaining consideration from the new allottee / purchaser.
Contentions of the Developer
13. The developer urged, in response to the complainant's appeal,
as well in its appeal, that no fault could be attached to it, and it could not
be fastened with any liability, once the Pay Order dated 30th April 2005
was received by the complainant. It was urged by senior counsel for the
developer that this court had carefully restricted the remand to whether
any liability arose due to any fault or deficiency on its part, after April
2005, given that the Pay Order was not encashed by the complainant. In
this connection, it was submitted that Citibank had categorically averred
that the amount was deducted from the developer's account, when the
Pay Order was issued. The bank also stated that the amount did not
earn any interest, and was kept separately, in accordance with instructions
and directives of the Reserve Bank of India (hereinafter, "RBI"). The
developer became aware that the Pay Order was part of the complaint
filed before the MRTP Commission for the first time on 29th April 2016,
when a statement was made by the complainant's counsel.
14. It was submitted that this court recorded that the Pay Order
was on the file of the MRTP Commission, and consequently permitted
its revalidation. It was in these circumstances, that the developer
approached the Commission, resulting in revalidation and subsequent
handing over of the instrument to the complainant.
A
B
C
D
E
F
G
H
1087
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
15. All these facts clearly established that the developer was not
at fault; the complainant in fact acknowledged having received the Pay
Order, returned by the developer, through letter dated 26th September
2005. Learned counsel relied on the pleadings before the MRTP
Commission, and pointed out that the index to the complaint and the
documents filed along with it, nowhere mentioned or referred to the
original Pay Order.
16. It was submitted that having returned the amount, through the
medium of the Pay Order, the developer had no further obligation to pay
further interest thereafter. It was submitted that the complainant would
have been justified in stating, if the facts were such that the amount was
with the developer, or lying in its account. However, once the amount
was debited from its account, and the Pay Order was made over to the
complainant, who sought to return, it, but after that, was handed back
the Pay Order, the developer could not be held responsible.
17. Counsel for the developer relied on Order XXI Rule 1(4) and
(5) of the Code of Civil Procedure, 1908 (hereinafter, "CPC") to state
that once the amount in question was paid through the bank (i.e., through
an instrument issued by the bank, such as Demand Draft or Pay Order,
as opposed to a cheque, "drawn on a bank") the liability would cease.
Counsel for the developer relied on the decisions in Hindustan Paper
Corporation Ltd vs. Ananta Bhattacharjee4 and in Gurpreet Singh
vs. Union of India5.
Analysis and Conclusion
18. For deciding this appeal, it is unnecessary to recount the entire
spectrum of facts and analyse the rival contentions, so far as they relate
to the liability of the developer for the period prior to 30th April 2005.
The scope of the Tribunal's remit, in this case, was defined by this court's
final order in the appeal decided by it earlier.6 This court, after noticing
that the developer had applied for revalidation after the complainant had
urged before the court that the Pay Order had been deposited in the
MRT Commission, further noted that the instrument had been revalidated
in 2016 and the amount was credited to the account of the developer on
4 Hindustan Paper Corporation Ltd vs. Ananta Bhattacharjee, (2004) 6 SCC 213,
dated 28th April 2004.
5 Gurpreet Singh vs. Union of India, 2006 (8) SCC 457, dated 19th October 2006.
6 Supra note 3, para 9.
A
B
C
D
E
F
G
H
1088
SUPREME COURT REPORTS
[2023] 1 S.C.R.
22nd May 2016. The court then proceeded to frame the scope of the
remand in the following terms:
"...To that limited extent, we propose to send back the matters
to the tribunal. Therefore, these appeals are disposed of as
follows:
(1) Citibank NA represented by its manager, Jeevan Bharti
building 124 Connaught Circus, New Delhi will stand
impleaded as additional respondent in the complaint before
the Competition Appellate Tribunal, New Delhi.
(2) the builder shall pay the compensation worked out at the
rate of 15 percent compound interest up to 30-04-2005.
(3) whether there should be any compensation, and if so, what
should be the amount payable after 30-04-2005, and whether
the Citibank's liable to pay in interest to the account holder
(sic)by the Tribunal.
To the above limited extent we remit the matters to the
Competition Appellate Tribunal, New Delhi.
It will be open to the parties to take all available contentions
in respect of the issues limited to, the Tribunal."
19. It is quite evident from the above that, with respect to the 30th
April 2005 liability, this court had affirmed the findings of the COMPAT
and also negatived the contentions of the complainant's legal heirs to the
extent that separate compensation other than compound interest was
payable. The developer was therefore directed to pay as a measure of
compensation compound interest at 15% per annum for the entire period,
i.e., 1993 to 2005. Since this court was apprised of the fact that the
complainant had deposited the Pay Order before the MRTP Commission,
it thought it appropriate to call for details from Citibank. After considering
the affidavit and the materials placed before it, this court decided that
the appropriate course would be to limit the matter to consider whether
for the duration after 2005, any liability could be attached to the developer.
That was the rationale for the limited scope of the remand.
20. The materials on record would disclose that in this case, after
issuing notice, the complainant returned the Pay Order received by her
under cover of letter dated 7th September 2005, however, the developer
A
B
C
D
E
F
G
H
1089
7 Supra note 3.
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
(in response to the complainant's notice), by letter dated 26th September
2005, denied the allegations contained in the notice and also returned the
Pay Order for ` 4,53,750/- and the banker's cheque for ` 1 lakh. It is
also evident that on 7th October 2005, the complaint was filed. A copy of
the complaint is on record. Curiously, it contains no mention of the Pay
Order, nor does it say that the complainant filed the Pay Order in original
along with the pleading. This is an undeniable fact. Even the counter
affidavit filed by the complainant in the developer's appeal states that
she:
"Bonafidely also deposited the Pay Orders dated 30-04-2005
in the registry along with the complaint under protest in
court."
21. Since the pleadings in the complaint did not refer to the Pay
Order, which was attached in the original along with the complaint, the
developer's reply too was silent on this aspect. This is evident from a
bare reading of the reply to the complaint before the MRTP Commission
filed by the developer on 3rd February 2006. Likewise, the reply to the
Notice of Enquiry, which was issued by the MRTP Commission, and
filed by the developer (supported by affidavit dated 25th January 2007)
also does not allude to the Pay Order.
22.In the previous proceedings before this court, in the
complainant's appeal,7 this court's order, dated 29th April 2016 reads as
follows:
"The learned counsel for the appellant submits that the
Demand Drafts furnished by the respondents have already
been deposited before the MRTP Commission. The respondents
are free to move the Competition commission for withdrawal
of the amount.
We record the statement of the appellant that in case, such an
attempt is made by the respondents, the appellant shall not
object the withdrawal of the drafts/amounts".
23.In terms of the leave granted by this court, through that order,
the developer moved an application before the COMPAT, which issued
the following directions on 18th May 2016:
A
B
C
D
E
F
G
H
1090
SUPREME COURT REPORTS
[2023] 1 S.C.R.
"This is an application on behalf of respondent Nos. 1 and 2
for release of Pay Order No. 885894 dated 30.04.2005 for
Rs.4,53,750/- drawn in favour of Dr. (Mrs.) Manjeet Kaur
Monga for revalidation thereof in the name of the legal
representatives of Dr. (Mrs.) Manjeet Kaur Monga.
Shri Aditya Narain, learned counsel for the applicants states
that his client will be satisfied if the pay order deposited in
2005 is returned to his client for the purpose of renewal, if
any, 1n accordance with. law. Learned counsel for the
representatives of the original complainant says that she does
not have any objection.
In view of the above, the application is allowed. The demand
Draft No. 885894 dated 30.04.2005 lying in the registry of
the Tribunal be returned to the applicants."
24.These developments were part of the record, and the court
was aware of them as a consequence of which the final order dated 18th
July 2017, disposing of the civil appeals, noted these facts:
"...During the course of hearing of the appeals another
interesting point came up for consideration. It has been
brought to the notice of this Court that when the builder
company, the appellant in the appeals arising out of SLP(C)
Nos.10484-10485/2016, had taken the pay order from the
Citibank on 30.04.2005, the amount of Rs.4,53,750/- covered
by the pay order had actually been deducted from their current
account. But at the same time, the amount had not been paid/
received by the payee. In the instant case, the account bolder
cancelled the pay order and requested for re-credit of the
amount and, accordingly, it is seen that the Citibank has recredited the amount to the account only on 22.06.2016. It is
the contention of the account holder company that for the
period the money was with the Bank, the account holder is
entitled to interest and that can be the compensation if at all
that can be paid to the appellant in Civil Appeal Nos.503233/2016 for the period after the cancellation of the allotment.
We may, of course, take note of the submission of the builder
that in terms of the principles of restitution under Section
144 C.P.C. and on the general principle of restitution, the
A
B
C
D
E
F
G
H
1091
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
builder cannot be put to unmerited injustice and the appellant
should not take the undue advantage as held by this Court in
Citibank N.A. v. Hiten P. Dalal and Others, (2016) 1 SCC
411, as canvassed by the learned counsel appearing for the
builder.
7. Learned counsel appearing for Citibank, inviting our
reference to the additional affidavit contended that it is a
fact that the money from the current account of the builder
has been deducted on 30. 04. 2005 and it has not been paid
to the payee. But, at the same time, it cannot be said that the
money was enjoyed by the Bank, since being a pay order, at
any moment the instrument is presented, the Bank was bound
to honour the same and, therefore, only for the lapse on the
part of either the payee or the account holder for encashing
or cancelling the instrument, the Bank cannot be saddled with
any interest. It is also submitted by the learned counsel
appearing for the Bank that they are governed by the
instructions issued by the Reserve Bank of India in that regard.
8. We find from the order of the Tribunal that both the issues
have not been gone into, apparently because these aspects
have not been canvassed and obviously because the Citibank
was not before the Tribunal."
25. The counter affidavit filed by the complainant, to the developer's
appeal presently before us, contains the following averments:
"It is reiterated that the said Pay Order was sent by the
Appellant No.2 to Respondent No. 1 vide cancellation letter
dated 30.04.2005. Thereafter, the same was returned by
Respondent No. l to the Appellants vide legal notice dated
07.09.2005 following which the Appellants once again
returned the same back to Respondent No. l vide their reply
to the legal notice dated 26.09.2005. It is submitted that the
Respondent No. 1 then filed a Complaint under section 36 of
the MRTP Act before the Ld. MRTP Commission and deposited
the said Pay Order dated 30.04.2005 in protest before the
Ld. MRTP Commission along with the said Complaint."
26. A consideration of the pleadings and other materials points to
the fact that the complainant did not state anywhere, before the MRTP
A
B
C
D
E
F
G
H
1092
SUPREME COURT REPORTS
[2023] 1 S.C.R.
Commission, that the original Pay Order was attached with the
pleadings. Interestingly, the index or cover page to the complaint was
made part of the additional written submissions of the developer dated
12th February 2018 (before the NCLAT). This index to the pleadings in
the complaint did not refer to the Pay Order. It cannot be for a moment
disputed that the complainant was perhaps under a belief that filing such
an original Pay Order established that she was not interested in receiving
refund, but was interested only to secure possession of the flat.
Nevertheless, it was necessary for her to apply through counsel for
an appropriate order to ensure that the amount was deposited in an
interest-bearing account. That step unfortunately was not taken -
perhaps she was not advised to do so. It was only when for the first time
when this was highlighted in the previous proceedings on 29th April 2016,
that the developer sought and obtained permission to apply to the
COMPAT for revalidation. The order facilitating that step was made on
18th May 2016, and eventually the Pay Order was revalidated on 22nd
June 2016.
27. From the impugned order, it is evident that the Tribunal accepted
the explanation of Citibank that since the Pay Order in question had
become stale, its proceeds / funds were moved to its 'Unclaimed Sundry
Account', and did not attract any interest in terms of the RBI directions.
The bank had also deposed that the Pay Order was cancelled on the
request of the developer through its letter dated 26th May 2016 and that
the funds were credited back to the account of the developer on 16th
June 2016. It was further noticed that the amount for issuing the Pay
Order was deducted from the current account of the developer. After
noticing these facts, the Tribunal appears to have been swayed by the
circumstance that the developer was held liable for unfair trade practice,
and directed to pay compensation (in terms of the previous orders of the
COMPAT) affirmed by this court, i.e., 15% compound interest on
` 4,53,750/-.
28.In the opinion of this court, the impugned order has not rested
its findings on any principle of law, much less any statutory provision.
The Tribunal appears to have been completely swayed by the
complainant's plight. In doing so, it did not give due consideration to the
fact that ` 4,53,750/- was debited from the account of the developer.
The complainant, for reasons best known to her, filed the original Pay
Order due to perhaps lack of proper advice or instruction. Apparently,
A
B
C
D
E
F
G
H
1093
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
no order contemporaneously was sought from the MRTP Commission,
which would have protected the interests of the complainant with respect
to the money received even while ensuring that her contentions on the
merits with respect to entitlement towards the flat were preserved. Many
avenues / alternatives were available. Firstly, the complainant could
have sought for a deposit of the proceeds of the Pay Order in an account,
to be maintained by the Registrar of the Commission. Secondly, she
could have sought for a 'without prejudice' order enabling her to encash
the amount, and at the same time ensure that her claim was not defeated
on that score. Thirdly, equally, she could have sought for appropriate
orders that the amount be maintained by the developer, who could, in the
event it became necessary, be directed to pay the principal along with
such interest as the Commission or the Tribunal deemed appropriate and
in the interests of justice. Since none of these choices were opted for,
and also having regard to the fact that the amount in question was
undoubtedly debited from the developer's current account, there ought
to have been a discussion of what was the applicable legal provision
which fastened any liability upon the developer. This was more important
because the Tribunal in the present case has accepted Citibank's
explanation regarding interest (or rather, its absence of liability, even
though the amount was undoubtedly with the bank for about 11 years).
29. This court, in Gurpreet Singh (supra), observed in the context
of Order XXI of CPC8 (which deals with modes of payment under
8 ORDER XXI Execution of Decrees and Orders Payment under Decree
1. Modes of paying money under decree.- (1) All money, payable under a decree shall
be paid as follows, namely:-
(a) by deposit into the court whose duty it is to execute the decree, or sent to that Court
by postal money order or through a bank; or
(b) out of Court, to the decree-holder by postal money order or through a bank or by
any other mode wherein payment is evidenced in writing; or
(c) otherwise, as the Court which made the decree, directs.
(2) Where any payments is made under clause (a) or clause (c) of sub-rule (1), the
judgment-debtor shall give notice thereof to the decree-holder either through the Court
or directly to him by registered post, acknowledgment due.
(3) Where money is paid by postal money order or through a bank under clause (a) or
clause (b) of sub-rule (1), the money order or payment through bank, as the case may
be, shall accurately state the following particulars, namely:-
(a) the number of the original suit;
(b) the names of the parties or where there are more than two plaintiffs or more than two
defendants, as the case may be, the names of the first two plaintiffs and the first two
defendants;
A
B
C
D
E
F
G
H
1094
SUPREME COURT REPORTS
[2023] 1 S.C.R.
decrees and also stipulates when interest shall cease to "run" (i.e., not
be payable)) as follows:
"Thus, in cases of execution of money decrees or award
decrees, or rather, decrees other than mortgage decrees,
interest ceases to run on the amount deposited, to the extent
of the deposit. It is true that if the amount falls short, the
decree holder may be entitled to apply the rule of
appropriation by appropriating the amount first towards the
interest, then towards the costs and then towards the principal
amount due under the decree. But the fact remains that to the
extent of the deposit, no further interest is payable thereon to
the decree holder and there is no question of the decree holder
claiming a re-appropriation when it is found that more amounts
are due to him and the same is also deposited by the judgment
debtor. In other words, the scheme does not contemplate a
reopening of the satisfaction to the extent it has occurred by
the deposit. No further interest would run on the sum
appropriated towards the principal.
As an illustration, we can take the following situation.
Suppose, a decree is passed for a sum of Rs. 5,000/- by the
trial court along with interest and costs and the judgment
debtor deposits the same and gives notice to the decree holder
either by approaching the executing court under Order XXI
Rule 2 of the Code or by making the deposit in the execution
taken out by the decree-holder under Order XXI Rule 1 of the
Code. The decree holder is not satisfied with the decree of
(c) how the money remitted is to be adjusted, that is to say, whether it is towards the
principal, interest or costs;
(d) the number of the execution case of the Court, where such case is pending; and
(e) the name and address of the payer.
(4) On any amount paid under clause (a) or clause (c) of sub-rule (1), interest, if any,
shall cease to run from the date of service of the notice referred to in sub-rule (2).
(5) On any amount paid under clause (b) of sub-rule (1), interest, if any, shall cease to
run from the date of such payment:
Provided that, where the decree-holder refuses to aceept the postal money order or
payment through a bank, interest shall cease to run from the date on which the money
was tendered to him, or where he avoids acceptance of the postal money order or
payment through bank, interest shall cease to run from the date on which the money
would have been tendered to him in the ordinary course of business of the postal
authorities or the bank, as the case may be."
A
B
C
D
E
F
G
H
1095
K. L. SUNEJA & ANR. v. DR. (MRS.) MANJEET KAUR
MONGA (D) THROUGH HER LR [S. RAVINDRA BHAT, J.]
the trial court. He goes up in appeal and the appellate court
enhances the decree amount to Rs. 10,000/- with interest and
costs. The rule in terms of Order XXI Rule 1, as it now stands,
in the background of Order XXIV would clearly be, that the
further obligation of the judgment debtor is only to deposit
the additional amount of Rs. 5,000/- decreed by the appellate
court with interest thereon from the date the interest is held
due and the costs of the appeal. The decree holder would not
be entitled to say that he can get further interest even on the
sum of Rs. 5,000/- decreed by the trial court and deposited
by the judgment debtor even before the enhancement of the
amount by the appellate court or that he can re-open the
transaction and make a re-appropriation of interest first on
Rs. 10,000/-, costs and then the principal and claim interest
on the whole of the balance sum again. Certainly, at both
stages, if there is short-fall in deposit, the decree holder may
be entitled to apply the deposit first towards interest, then
towards costs and the balance towards the principal. But that
is different from saying that in spite of his deposit of the
amounts decreed by the trial court, the judgment debtor would
still be liable for interest on the whole of the principal amount
in case the appellate court enhances the same and awards
interest on the enhanced amount."
30.The rule was explained in another decision of this court, in V.
Kala Bharathi & Ors.