# PARSA KENTE COLLIERIES LIMITED v. RAJASTHAN RAJYA VIDYUT UTPADAN NIGAM LIMITED

- **Citation:** [2019] 8 S.C.R. 728
- **Court:** Supreme Court of India
- **Decided:** 2019-05-27
- **Case number:** Civil Appeal No. 9023 of 2018
- **Bench:** Arun Mishra, M. R. Shah
- **Source:** https://unisonlegal.in/judgment/supreme-court-of-india/parsa-kente-collieries-limited-v-rajasthan-rajya-vidyut-utpadan-nigam-limited-34078
- **Pages:** 18

## Headnote

Arbitration and Conciliation Act, 1996: s. 37 - Appeal under
- Jurisdiction of the appellate court while considering the award
passed by the arbitrator - Coal Mining and Delivery Agreement
between the appellant and the respondent for supply of coal -
Disputes between the parties, as regards the escalation price, fixed
costs, amount lying in escrow account and cost of construction of
railway siding - Award by arbitrator allowing the claims under the
heads of 'price adjustment', 'fixed costs' and 'escrow account',
however, rejected under the head 'construction of railway siding' -
Award confirmed by the commercial court, however, set aside by the
High Court - Justification of - On appeal, held: With respect to
claim no.1-price adjustment/escalation, interpretation by the
arbitrator was both possible as well as plausible - Merely because
some other view could have been taken, the High Court was not
justified in interfering with the interpretation -Though the High
Court observed that the award passed by the arbitrator with respect
to claim no.1 was against the public policy, but there was no element
of public policy - High Court exceeded in its jurisdiction in
interfering with the award passed by the arbitrator as regards claim
no. 1 - With respect to claim no.2-fixed costs, the High Court rightly
set aside the award passed by the arbitrator - Except the CA's
certificate, no further evidence had been led with respect to actual
loss - On the contrary, in the relevant year the quantity of the coal
lifted by the respondent was much above the fixed quantity - As
regards, claim no.3-escrow account, the object and purpose of
opening the escrow account was to see that the appellant company
fulfils the contract as per the agreement and till the closure of the
coal blocks - It was not open for the appellant to claim the amount
lying in the escrow account, else the object of opening the escrow
account would be frustrated - Thus, with respect to claim no.3-
 [2019] 8 S.C.R. 728
728
A
B
C
D
E
F
G
H
729
escrow account, the High Court rightly held the reasoning is perverse
or so irrational that no reasonable person could have arrived at on
the material/evidence on record - Thus, the order passed by the
High Court as regards claim no. 1 is set aside and the award passed
by the arbitrator with respect to claim no.1 is restored and the order
passed by the High Court setting aside the award with respect to
claim no.2-fixed costs and claim no.3-escrow account is upheld.
Partly allowing the appeal, the Court
HELD: 1.1 So far as the claim with respect to "price
adjustment/escalation" is concerned, the arbitrator held that the
date of commencement of the first operating year for the purposes
of clauses 5.2.2 read with 5.4.3 would be 25.06.2011 and therefore
zero year for the purpose of price escalation has to be 2011-12.
Accordingly, the arbitrator considered the escalated price in F.Y.
2013-14 at Rs.895/- per MT. However, according to the
respondent, as the date of commencement was changed from
25.06.2011 to 25.03.2013, the zero year for the purpose of price
escalation would be 2013-14. Price escalation is permissible under
the contract/agreement itself and there shall be price escalation
every year as per the formulae mentioned in the agreement,
commencing from the date of commencement. However, it is true
that the initial date of commencement, i.e., 25.06.2011 came to
be extended to 25.03.2013 by mutual agreement. However, the
same was due to force majeure as there was a delay of 21 months
in obtaining the forest clearance and environmental clearance.
The price was quoted in the year 2007-08, applicable from 2011.
However, there was a delay in obtaining the forest clearance and
environmental clearance and therefore the date of
commencement of supply came to be changed. In between there
would be hike in labour charges, transportation charges, etc.
Though the date of commencement of supply was extended, there
was no corresponding amendment in the

## Text

_Characters 0–39,860 of 42,889. This is a partial read: ask again with offset=39860 for what follows._

A
B
C
D
E
F
G
H
728
SUPREME COURT REPORTS
[2019] 8 S.C.R.
PARSA KENTE COLLIERIES LIMITED
v.
RAJASTHAN RAJYA VIDYUT UTPADAN NIGAM LIMITED
(Civil Appeal No. 9023 of 2018)
MAY 27, 2019
[ARUN MISHRA AND M. R. SHAH, JJ.]
Arbitration and Conciliation Act, 1996: s. 37 - Appeal under
- Jurisdiction of the appellate court while considering the award
passed by the arbitrator - Coal Mining and Delivery Agreement
between the appellant and the respondent for supply of coal -
Disputes between the parties, as regards the escalation price, fixed
costs, amount lying in escrow account and cost of construction of
railway siding - Award by arbitrator allowing the claims under the
heads of 'price adjustment', 'fixed costs' and 'escrow account',
however, rejected under the head 'construction of railway siding' -
Award confirmed by the commercial court, however, set aside by the
High Court - Justification of - On appeal, held: With respect to
claim no.1-price adjustment/escalation, interpretation by the
arbitrator was both possible as well as plausible - Merely because
some other view could have been taken, the High Court was not
justified in interfering with the interpretation -Though the High
Court observed that the award passed by the arbitrator with respect
to claim no.1 was against the public policy, but there was no element
of public policy - High Court exceeded in its jurisdiction in
interfering with the award passed by the arbitrator as regards claim
no. 1 - With respect to claim no.2-fixed costs, the High Court rightly
set aside the award passed by the arbitrator - Except the CA's
certificate, no further evidence had been led with respect to actual
loss - On the contrary, in the relevant year the quantity of the coal
lifted by the respondent was much above the fixed quantity - As
regards, claim no.3-escrow account, the object and purpose of
opening the escrow account was to see that the appellant company
fulfils the contract as per the agreement and till the closure of the
coal blocks - It was not open for the appellant to claim the amount
lying in the escrow account, else the object of opening the escrow
account would be frustrated - Thus, with respect to claim no.3-
 [2019] 8 S.C.R. 728
728
A
B
C
D
E
F
G
H
729
escrow account, the High Court rightly held the reasoning is perverse
or so irrational that no reasonable person could have arrived at on
the material/evidence on record - Thus, the order passed by the
High Court as regards claim no. 1 is set aside and the award passed
by the arbitrator with respect to claim no.1 is restored and the order
passed by the High Court setting aside the award with respect to
claim no.2-fixed costs and claim no.3-escrow account is upheld.
Partly allowing the appeal, the Court
HELD: 1.1 So far as the claim with respect to "price
adjustment/escalation" is concerned, the arbitrator held that the
date of commencement of the first operating year for the purposes
of clauses 5.2.2 read with 5.4.3 would be 25.06.2011 and therefore
zero year for the purpose of price escalation has to be 2011-12.
Accordingly, the arbitrator considered the escalated price in F.Y.
2013-14 at Rs.895/- per MT. However, according to the
respondent, as the date of commencement was changed from
25.06.2011 to 25.03.2013, the zero year for the purpose of price
escalation would be 2013-14. Price escalation is permissible under
the contract/agreement itself and there shall be price escalation
every year as per the formulae mentioned in the agreement,
commencing from the date of commencement. However, it is true
that the initial date of commencement, i.e., 25.06.2011 came to
be extended to 25.03.2013 by mutual agreement. However, the
same was due to force majeure as there was a delay of 21 months
in obtaining the forest clearance and environmental clearance.
The price was quoted in the year 2007-08, applicable from 2011.
However, there was a delay in obtaining the forest clearance and
environmental clearance and therefore the date of
commencement of supply came to be changed. In between there
would be hike in labour charges, transportation charges, etc.
Though the date of commencement of supply was extended, there
was no corresponding amendment in the relevant clauses of the
agreement with respect to price escalation. There was no specific
agreement that in the year 2013, the appellant would supply the
coal at the same price, without any price escalation. Therefore,
considering the overall facts and circumstances of the case and
by giving cogent reasons, the arbitrator interpreted the relevant
clauses of the contract and specifically held that the date of
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD.
A
B
C
D
E
F
G
H
730
SUPREME COURT REPORTS
[2019] 8 S.C.R.
commencement of the first operating year for the purposes of
clauses 5.2.2 read with 5.4.3 would be 25.06.2011 and accordingly
the zero year for the purpose of price escalation would be 201112 and therefore the appellant shall be entitled to the enhanced
amount as is applicable in the year 2013-14 (the price escalation).
Having considered the reasoning given by the arbitrator, the
interpretation by the arbitrator was both possible as well as
plausible. Therefore, merely because some other view could have
been taken, the High Court is not justified in interfering with the
interpretation made by the arbitrator. Therefore, in the facts and
circumstances of the case, the High Court has clearly exceeded
in its jurisdiction in interfering with the award passed by the
arbitrator with respect to claim no.1-price adjustment/escalation.
Though the High Court has observed that the award passed by
the learned arbitrator with respect to claim no.1 was against the
public policy, with respect, there is no element of public policy. It
was pure and simple case of interpretation of the relevant clauses
of the agreement which does not involve any public policy.
Therefore, the impugned judgment and order passed by the High
Court for quashing and setting aside the award passed by the
arbitrator with respect to claim no.1-price adjustment/escalation
cannot be sustained and the same deserves to be quashed and
set aside. [Para 11.1] [743-D-H; 744-A-F]
1.2 So far as claim no.2-"fixed costs" and an amount of Rs.78
crores awarded by the arbitrator with respect to compensation of
loss is concerned, having gone through the relevant material on
record, the High Court has rightly set aside the award passed by
the arbitrator with respect to claim no.2. Except the CA's
certificate, no further evidence had been led with respect to actual
loss. Considering the material on record, it is on the contrary
found that in the relevant year the quantity of the coal lifted by
the respondent was much above the fixed quantity. Thus, the
award passed by the arbitrator with respect to claim no.2 was
contrary to the evidence on record and thus, is rightly set aside
by the High Court. [Para 11.2] [743-G-H; 744-B]
1.3 As regards claim no.3-"Escrow Account", the High
Court rightly interfered with the award passed by the arbitrator
A
B
C
D
E
F
G
H
731
with respect to claim no.3. The escrow account was required to
be opened as per the guidelines issued by the Ministry of Coal,
Government of India for the preparation of mine closure plant.
The guidelines required, inter alia, the mining company to open
an escrow account with any schedule bank. Accordingly, the
respondent opened an escrow account and executed an escrow
agreement. From the correspondence between the parties, it
appears that even the appellant consented for opening the escrow
account. The appellant also agreed that the amount to be
deposited in the escrow account will be recovered by the
respondent from immediate next payment of the coal bills of the
joint venture company-PKCL raised towards dispatches of coal
from appellant's coal blocks. Thus, thereafter it was not open for
the appellant to claim the amount lying in the escrow account. If
the amount lying in the escrow account is returned to the appellant,
the purpose and object of opening the escrow account which was
as per the guidelines of the Ministry of Coal would be frustrated.
The object and purpose of opening the escrow account was to
see that the appellant company fulfils the contract as per the
agreement and till the closure of the coal blocks. Therefore, the
High Court rightly interfered with the award passed by the
arbitrator with respect to claim no.3-escrow account by observing
that the reasoning is perverse or so irrational that no reasonable
person could have arrived at on the material/evidence on record.
[Para 11.3] [744-B-F]
1.4 The impugned judgment and order passed by the High Court
insofar as quashing and setting aside the award passed by the
sole arbitrator, insofar as claim no. 1-price adjustment/escalation
is quashed and set aside and the award passed by the arbitrator
with respect to claim no.1 is restored. The impugned judgment
and order by the High Court insofar as quashing and setting aside
the award passed by the arbitrator with respect to rest of the
claim no.2-fixed costs and claim no.3-escrow account is
confirmed. [Para 12] [744-G-H; 745-A-B]
Associate Builders v. Delhi Development Authority
(2015) 3 SCC 49 ; Steel Authority of India Limited v.
Gupta Brother Steel Tubes Limited (2009) 10 SCC 63 :
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD.
A
B
C
D
E
F
G
H
732
SUPREME COURT REPORTS
[2019] 8 S.C.R.
[2009] 14 SCR 253 ; Ssangyong Engineering &
Construction Co. Limited v. National Highways
Authority of India 2019 SCC Online SC 677 ; ONGC
v. Saw Pipes Limited (2003) 5 SCC 705 : [2003] 3 SCR
691 ; Hindustan Zinc Limited v. Friends Coal
Carbonisation (2006) 4 SCC 445 ; McDermott
International Inc. v. Burn Standard Co. Ltd. (2006) 11
SCC 181 : [2006] 2 Suppl. SCR 409 ; Rashtriya Ispat
Nigam Limited v. Dewan Chand Ram Saran (2012) 5
SCC 306 : [2012] 4 SCR 1 ; National Highways
Authority of India v. ITD Cementation India Limited
(2015) 14 SCC 21 : [2015] 6 SCR 107 ; Steel Authority
of India Limited v. Gupta Brother Steel Tubes Limited
(2009) 10 SCC 63 : [2009] 14 SCR 253 - referred to.
Case Law Reference
(2015) 3 SCC 49
referred to
Para 5.3
[2009] 14 SCR 253
referred to
Para 5.3
[2003] 3 SCR 691
referred to
Para 6.1
(2006) 4 SCC 445
referred to
Para 6.1
[2006] 2 Suppl. SCR 409
referred to
Para 9.1
[2012] 4 SCR 1
referred to
Para 9.1
[2015] 6 SCR 107
referred to
Para 9.2
[2009] 14 SCR 253
referred to
Para 9.2
CIVIL APPELLATE JURISDICTION : Civil Appeal No. 9023
of 2018.
From the Judgment and Order dated 28.02.2018 of the High Court
of Judicature for Rajasthan at Jaipur Bench, Jaipur in D. B. Civil Misc.
Appeal No. 3785 of 2017.
Ranjit Kumar, Vikram Nankani, Sr. Advs., Mahesh Agarwal,
Anurup Singh, Salil Sinha, Anshuman Srivastava, Rishi Raj Sharma, E.
C. Agrawala, Advs. for the Appellant.
Tushar Mehta, Solicitor General, Kartik Seth, Ankur S. Kulkarni,
Nishant Kumar, Advs. for the Respondents.
A
B
C
D
E
F
G
H
733
The Judgment of the Court was delivered by
M. R. SHAH, J.
1. Feeling aggrieved and dissatisfied with the impugned judgment
and order dated 28.02.2018 passed by the Commercial Appellate Court/
Division Bench of the High Court of Judicature for Rajasthan, Bench at
Jaipur in D.B. Civil Miscellaneous Appeal No. 3785 of 2017, by which
the High Court has allowed the said appeal preferred by the respondent
herein - Rajasthan Rajya Vidyut Utpadan Nigam Limited and has quashed
and set aside the award passed by the learned Arbitrator, confirmed by
the Commercial Appellate Court at Jaipur, the appellant - the original
claimant - Parsa Kente Collieries Limited has preferred the present
appeal.
2. That in the month of March, 2006, the respondent floated a
tender for joint venture to undertake coal block development, mining and
transportation of coal and delivery. That one Adani Enterprises Limited
(AEL) submitted a bid which was accepted on 12.05.2006. A Letter of
Intent was issued to AEL by the respondent on 23.10.2006. Respondent
and AEL entered into a joint venture, namely, Parsa Kente Collieries
Limited, the appellant herein. A Coal Mining Service Agreement was
entered into between the said Parsa Kente Collieries Limited and AEL.
That a Coal Mining and Delivery Agreement (hereinafter referred to as
'CMDA') was executed between the appellant and the respondent on
16.07.2008 for supply of coal.
2.1 As per CMDA, the date of commencement of the contract
was 25.06.2011. As per CMDA between the appellant and the respondent,
the coal supply was to commence at the earliest within 42 months, or
within 48 months from the date of allotment of coal blocks, i.e., by
25.06.2011. CMDA also provided a clause for extending the date of
commencement. Clause 3.2.1 of the CMDA provided for scope of
work; Clause 4.1.3 and 4.1.4 provided for responsibility of the respondent
to inform the appellant as regards the requirement of coal in advance.
Clause 4.5 provided for commencement of the date; clause 5.1 provided
for contract of price; clause 5.2.2. provided for calculation of basic price;
clause 5.4.3 provided for escalation in price; clause 7.1 provided for
force majeure and clause 7.3 provided for effect of force majeure. There
was a delay of 21 months in obtaining the forest clearance and
environmental clearance. The appellant started supply of coal to the
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD.
A
B
C
D
E
F
G
H
734
SUPREME COURT REPORTS
[2019] 8 S.C.R.
respondent with effect from 25.3.2013, i.e., after a delay of 21 months.
It appears that the date of commencement was extended by mutual
agreement from 25.6.2011 to 25.3.2013. However, certain disputes arose
between the parties, more particularly the escalation price, fixed costs,
amount lying in Escrow account and cost of construction of railway
siding. Therefore, the appellant invoked clause 10.2 of the CMDA and
sought arbitration. A retired Hon'ble Judge of the Rajasthan High Court
was appointed as the sole arbitrator. The appellant submitted the
statement of claim and thereafter filed another statement of claim.
2.2 Before the learned Arbitrator, the claim was bifurcated into
four heads, namely, (1) Price Adjustment; (2) Fixed Costs; (3) Escrow
Account; and (4) Construction of Railway Siding. The learned Arbitrator
passed an award dated 27.05.2015 allowing the claims under the heads
of 'Price Adjustment', 'Fixed Costs' and 'Escrow Account' and rejected
the claim under the head 'Construction of Railway Siding'. While allowing
the claim under the head 'Price Adjustment', the learned Arbitrator held
that the date of commencement of the first operating year for the
purposes of clauses 5.2.2 read with 5.4.3 would be 25.06.2011. The
learned Arbitrator further held that thus the Zero year for the purpose of
price escalation has to be 2011-2012. The learned Arbitrator accordingly
held that because the date of commencement of the agreement for the
purpose of price escalation is 25.06.2011, the appellant shall be entitled
to the enhanced amount as applicable in 2013-2014. Accordingly, the
learned Arbitrator held that the appellant is entitled to the coal price at
Rs.837/- PMT in F.Y. 2013-14 and thereafter the escalated price in the
subsequent years as per the relevant clauses of the contract - CMDA.
2.3 That while allowing the claim with respect to 'Fixed Costs',
the learned Arbitrator held that the respondent could not take the required
delivery of the coal from the appellant, thus causing loss to the appellant.
The learned Arbitrator held that therefore the appellant is entitled to
compensation as claimed for Rs.78 crores.
2.4 That while allowing the claim with respect to 'Escrow Account',
the learned Arbitrator held that the undertaking given by the appellant
was limited to a contingency where on account of failure of completion
of mine closure activity by the appellant led to the forfeiture of any
amount deposited in the escrow account, the respondent would be entitled
to recover the same from the monthly running bills of the appellant. The
learned Arbitrator observed, however, as no such occasion has arisen,
A
B
C
D
E
F
G
H
735
the question of any deduction on the said count does not arise.
Consequently, the learned Arbitrator directed the respondent to return
that amount which was lying in the escrow account which was deducted
from the monthly running bills of the appellant.
2.5 As observed hereinabove, the learned Arbitrator rejected claim
no.4, namely, under the head 'Construction of Railway Siding'. The
award declared by the learned Arbitrator came to be confirmed by the
learned Commercial Court, Jaipur in an application under section 34 of
the Arbitration and Conciliation Act.
3. Feeling aggrieved, the respondent preferred an appeal under
Section 37 of the Arbitration Act before the Commercial Appellate Court/
Division Bench of the High Court of Rajasthan at Jaipur. By the impugned
judgment and order dated 28.02.2018, the High Court has allowed the
said appeal and has set aside the award passed by the learned Arbitrator
and confirmed by the Commercial Court, Jaipur.
4. Feeling aggrieved by the impugned judgment and order passed
by the Division Bench of the High Court, the original claimant - the
appellant has preferred the present appeal.
5. Shri Ranjit Kumar, learned Senior Advocate has appeared on
behalf of the appellant and Shri Tushar Mehta, learned Solicitor General
of India has appeared on behalf of the respondent.
5.1 Shri Ranjit Kumar, learned Senior Advocate appearing on
behalf of the appellant has vehemently submitted that in the facts and
circumstances of the case, the High Court ought not to have interfered
with the concurrent findings of the learned sole Arbitrator and the learned
Commercial Court under Section 34 of the Arbitration Act by giving an
alternate construction to the CMDA. It is vehemently submitted that by
passing the impugned judgment and order, the High Court has exceeded
in its jurisdiction in interfering with the award passed by the learned
Arbitrator, confirmed by the learned Commercial Court, while exercising
the powers under Section 37 of the Arbitration Act.
5.2 It is further submitted by the learned Senior Advocate appearing
on behalf of the appellant that under Section 37 of the Arbitration Act,
the scope of judicial inquiry is narrow and does not entail giving own
construction to the contract. It is submitted by disturbing the findings,
the High Court has gone beyond the limited scope of inquiry contemplated
under Section 37 of the Arbitration Act.
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD. [M. R. SHAH, J.]
A
B
C
D
E
F
G
H
736
SUPREME COURT REPORTS
[2019] 8 S.C.R.
5.3 It is further submitted by the learned Senior Advocate appearing
on behalf of the appellant that the Division Bench of the High Court has
failed to appreciate that the interpretation made by the learned sole
Arbitrator on the clauses of CMDA was plausible construction/
interpretation and therefore the same could not have been substituted by
the High Court in exercise of powers under Section 37 of the Arbitration
Act.
In support of his above submissions, Shri Ranjit Kumar, learned
Senior Advocate has heavily relied upon the decisions of this Court in
the cases of Associate Builders v. Delhi Development Authority,
reported in (2015) 3 SCC 49; Steel Authority of India Limited v.
Gupta Brother Steel Tubes Limited, reported in (2009) 10 SCC 63
and the recent decision of this Court in the case of Ssangyong
Engineering & Construction Co. Limited v. National Highways
Authority of India (NHAI), rendered on 08.05.2019 in Civil Appeal
No. 4779 of 2019, reported in 2019 SCC Online SC 677.
5.3.1 It is further submitted by the learned Senior Advocate
appearing on behalf of the appellant that admittedly there was a delay of
21 months in supply of coal, which was due to the force majeure as
there was a delay in obtaining the forest clearance and environmental
clearance. It is submitted that the price which was agreed by the
appellant in the year 2008 to be paid in the year 2011 would never remain
the same in the year 2013-14. It is submitted that therefore though the
commencement date as per CMDA was extended due to an admitted
fact of force majeure to 25.3.2013, the commencement date would
remain as the date defined under the CMDA, i.e., 25.06.2011 and
therefore the price escalation ought to be considered from that date.
5.3.2 It is further submitted by the learned Senior Advocate
appearing on behalf of the appellant that though by mutual agreement
the commencement date was extended due to an admitted fact of force
majeure to 25.03.2013, there was no agreement to supply the coal at
the same price which was to be supplied in the year 2011. It is submitted
that there is a specific clause - clause 4.5.2 which allows extension of
commencement date in cases of force majeure, however, no such
corresponding clause has been provided in clause 5.4.3, which is a clause
for price escalation. It is submitted that the intention of parties was
never to unilaterally extend the first operating year referred to in clause
A
B
C
D
E
F
G
H
737
5.2.2. It is submitted that therefore the price escalation has to be
necessarily applied from the contractually stipulated date, i., 25.06.2011.
5.3.3 It is submitted that in any case the interpretation by the
learned Arbitrator was plausible and as such was equitable also. Merely
because some other view was possible, the High Court is not justified in
interfering with the interpretations/findings recorded by the learned sole
Arbitrator and that too in exercise of powers under Section 37 of the
Arbitration Act. It is submitted that the interpretation of the relevant
clauses of the CMDA with respect to claim no.1 was actually in
consonance with the relevant clauses of the CMDA. It is submitted
therefore the High Court has erred in interfering with the award passed
by the learned Arbitrator, confirmed by the learned Commercial Court.
5.4 Now so far as claim no.2 under the head 'Fixed Costs' is
concerned, Shri Ranjit Kumar, learned Senior Advocate has heavily relied
upon clause 8.2(iii) of the CMDA. It is submitted that due to the lapse
on the part of the respondent, the respondent was unable to take delivery
of the coal for the financial year 2013-14. It is submitted that there was
an event of default by the respondent as contemplated in clause 8.2(iii)
of the CMDA.
5.4.1 It is submitted that due to inability of the respondent to take
coal as per the stipulated delivery schedule, the appellant had to operate
its plant at a sub-optimal level which resulted in incurring fixed costs. It
is submitted that it was mandatory for the coal to be lifted within 3
months of production to prevent spontaneous combustion and to ensure
that there is no hazard to the plant. It is submitted that despite this, the
respondent failed to take delivery.
5.4.2 It is further submitted by the learned Senior Advocate
appearing on behalf of the appellant that the High Court has committed
an error by not granting the said claim on the ground that the loss was
incurred by AMPL (sub-contractor) under Coal Mining Services
Agreement to which the respondent was not a party and secondly that
loss of Rs.78 crores is not substantiated beyond the Chartered
Accountant's certificate. It is further submitted by the learned Senior
Advocate appearing on behalf of the appellant that CMDA does not
prohibit appointment of AMPL as a sub-contractor and in fact any such
appointment was approved by the appellant and therefore AMPL cannot
be said to be a complete third party to the CMDA. It is submitted that
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD. [M. R. SHAH, J.]
A
B
C
D
E
F
G
H
738
SUPREME COURT REPORTS
[2019] 8 S.C.R.
therefore when the respondent failed to lift the fixed quantity of the coal
and there was a delay in taking the delivery of the coal for the F.Y.
2013-14, the appellant shall be entitled to the loss suffered to the extent
of Rs.78 crores. It is submitted therefore the High Court has committed
a grave error in disallowing the said claim.
5.5 Now so far as claim no.3 under the head 'Escrow Account' is
concerned, it is submitted by the learned Senior Advocate appearing on
behalf of the appellant that the High Court has erroneously held that the
respondent was entitled to make deductions from the appellant's bills for
payments made in the escrow account. It is submitted that as such the
learned sole Arbitrator rightly came to a conclusion that the stage of
closing of mines had not been arrived at and therefore the deductions to
make the payments into escrow account were premature. It is submitted
that the issue of deduction would arise only after a passage of 30 years
at the time of closure of the mining plant. It is further submitted that the
deposit of amount in the escrow account had arisen due to the guidelines
issued by the Ministry of Coal, which was subsequent to the execution
of the CMDA. It is submitted that therefore the said circular issued by
the Ministry of Coal would not bind the parties to the CMDA. It is
submitted therefore the High Court has committed a grave error in
rejecting claim no.3.
5.6 Making the above submissions and relying upon the above
decisions, it is prayed to allow the present appeal.
6. Shri Tushar Mehta, learned Solicitor General of India, while
opposing the present appeal, has vehemently submitted that in the facts
and circumstances of the case and having found that the claims allowed
by the learned sole Arbitrator, confirmed by the learned Commercial
Court, were just contrary to the relevant clauses of the CMDA, the
High Court is justified in reversing the award passed by the learned
Arbitrator, confirmed by the learned Commercial Court.
6.1 It is vehemently submitted by the learned Solicitor General
that as per the settled proposition of law, the learned Arbitrator cannot
substitute the terms of the contract and/or interpret the relevant clauses
of the contract, which would make the relevant clauses of the contract
nugatory. It is submitted that the award, by standing in complete
contravention of clear and express provisions of the CMDA, is in conflict
with the public policy of India. It is submitted that in the present case,
A
B
C
D
E
F
G
H
739
according to the respondent, regarding the "commencement date", there
was only one possible interpretation that could have been accepted by
the learned arbitrator. It is submitted that however the interpretation
that has been upheld by the learned arbitrator, apart from being devoid
of any reasoning in its support, is wholly incompatible with the terms of
the CMDA and the conduct of the parties. It is submitted that any
award, by standing in complete contravention of clear and express
provisions of the CMDA, is in conflict with the public policy of India and
therefore is liable to be set aside. It is submitted therefore the High
Court has rightly set aside the award in exercise of powers under Section
37 of the Arbitration Act. In support of his above submissions, Shri
Tushar Mehta, learned Solicitor General of India has heavily relied upon
the decision of this Court in the case of ONGC v. Saw Pipes Limited,
reported in (2003) 5 SCC 705; Hindustan Zinc Limited v. Friends
Coal Carbonisation, reported in (2006) 4 SCC 445 and Associate
Builders v. DDA, reported in (2015) 3 SCC 49.
6.2 Now so far as claim no.1, namely, price escalation is concerned,
it is vehemently submitted by Shri Tushar Mehta, learned Solicitor General
that the term "commencement date" has been defined in the agreement
to have the same meaning as given to it in clause 4.5.1. It is submitted
that as per clause 4.5.3 the date of commencement is the essence to the
contract. It is submitted that as per the relevant clauses of the CMDA,
the commencement date was extendable and in fact with the mutual
agreement the same was extended to 25.03.2013. It is submitted that
the term "commencement date" is defined to be the date on which the
actual supply of coal begins. It is submitted that in the present case,
admittedly, the date of supply of the coal is 25.03.2013, and therefore,
the appellant shall be entitled to escalation in price only after the completion
of 12 months from the commencement date, i.e., 25.03.2013. It is
submitted under the CMDA, the appellant is entitled to the escalation in
price in each operating year provided that the first escalation shall occur
only after completion of 12 months from the commencement date, i.e.,
25.03.2013. It is submitted that thus any escalation in price is linked to
the date of commencement of coal supply. It is submitted that thus if the
coal supply is commenced as planned on 25.06.2011, the first operating
year would have been 25.06.2011 to 31.03.2012. However, since coal
supply only commenced on 25.03.2013, the first operating year ought to
have been 25.03.2013 to 31.03.2013. It is submitted therefore that when
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD. [M. R. SHAH, J.]
A
B
C
D
E
F
G
H
740
SUPREME COURT REPORTS
[2019] 8 S.C.R.
the commencement date is 25.06.2011, the first price escalation would
be applicable for the F.Y. 2013-14. It is submitted that however if the
commencement date is held to be 25.03.2013 (which in fact was
extended by mutual agreement), the first price escalation would occur in
F.Y. 2014-15. It is submitted that it is evident from clause 5.4.3 of the
CMDA that an escalation in price was to be made only after the delivery
of coal had commenced and it is an admitted fact that actual supply of
coal started on 25.03.2013. It is submitted therefore that there is no
question of price escalation for F.Y. 2013-14. It is submitted that therefore
the award passed by the learned Arbitrator was just contrary to the
relevant clauses of the CMDA and therefore the same is rightly set
aside by the High Court.
6.3 It is further submitted by the learned Solicitor General of India
that in fact the respondent lifted the full quantity of the fixed quantity
and therefore there was no loss and in fact the appellant failed to adduce
any evidence with respect to the actual loss either due to delay in lifting
the coal and/or lifting the loss quantity of the coal than they agreed. The
same is rightly set aside by the High Court.
6.4 It is further submitted by the learned Solicitor General
appearing on behalf of the respondent that similarly the High Court has
rightly set aside the claim with respect to "escrow account". It is
submitted that as such the "escrow account" was required to be opened
as per the circular issued by the Ministry of Coal. It is submitted that, in
fact, the appellant consented to open the escrow account which as such
was required to be opened as per the guidelines issued by the Ministry
of Coal. It is submitted that therefore in fact the appellant consented
that the money is being recovered from its running bills to be deposited
in the escrow account. It is submitted that even the same is in consonance
with clause 3.2.1 of the CMDA. It is submitted therefore the High
Court has rightly disallowed the said claim made in escrow account.
6.5 Making the above submissions and relying upon the above
decisions, it is prayed to dismiss the present appeal.
7. We have heard the learned counsel for the respective parties
at length.
8. At the outset, it is required to be noted that by the impugned
judgment and order, the Division Bench of the High Court in exercise of
its powers under Section 37 of the Arbitration Act has set aside the
A
B
C
D
E
F
G
H
741
award passed by the learned Arbitrator, confirmed by the learned
Commercial Court.
Therefore, the short question which is posed for consideration
before this Court is, whether in the facts and circumstances of the case,
the Division of the High Court is justified in interfering with the award
passed by the learned Arbitrator, confirmed by the learned Commercial
Court, in an appeal under Section 37 of the Arbitration Act?
9. While answering the aforesaid question, certain decisions of
this Court and the law declared on the jurisdiction of the appellate Court
while considering the award passed by the learned Arbitrator are required
to be considered.
9.1 In the case of Associate Builders (supra), this Court had an
occasion to consider in detail the jurisdiction of the Court to interfere
with the award passed by the Arbitrator in exercise of powers under
Section 34 of the Arbitration Act. In the aforesaid decision, this Court
has considered the limits of power of the Court to interfere with the
arbitral award. It is observed and held that only when the award is in
conflict with the public policy in India, the Court would be justified in
interfering with the arbitral award. In the aforesaid decision, this Court
considered different heads of "public policy in India" which, inter alia,
includes patent illegality. After referring Section 28(3) of the Arbitration
Act and after considering the decisions of this Court in the cases of
McDermott International Inc. v. Burn Standard Co. Ltd., reported
in (2006) 11 SCC 181 (paras 112-113) and Rashtriya Ispat Nigam
Limited v. Dewan Chand Ram Saran, reported in (2012) 5 SCC 306
(paras 43-45), it is observed and held that an arbitral tribunal must
decide in accordance with the terms of the contract, but if an arbitrator
construes a term of the contract in a reasonable manner, it will not mean
that the award can be set aside on this ground. It is further observed
and held that construction of the terms of a contract is primarily for an
arbitrator to decide unless the arbitrator construes the contract in such a
way that it could be said to be something that no fair minded or reasonable
person could do. It is further observed by this Court in the aforesaid
decision in paragraph 33 that when a court is applying the "public policy"
test to an arbitration award, it does not act as a court of appeal and
consequently errors of fact cannot be corrected. A possible view by the
arbitrator on facts has necessarily to pass muster as the arbitrator is the
ultimate master of the quantity and quality of evidence to be relied upon
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD. [M. R. SHAH, J.]
A
B
C
D
E
F
G
H
742
SUPREME COURT REPORTS
[2019] 8 S.C.R.
when he delivers his arbitral award. It is further observed that thus an
award based on little evidence or on evidence which does not measure
up in quality to a trained legal mind would not be held to be invalid on this
score.
9.2 Similar is the view taken by this Court in the cases of National
Highways Authority of India v. ITD Cementation India Limited,
reported in (2015) 14 SCC 21(para 25) and Steel Authority of India
Limited v. Gupta Brother Steel Tubes Limited, reported in (2009) 10
SCC 63 (para 29).
10. Applying the law laid down by this Court, we have to examine
whether the Division Bench of the High Court has exceeded in its
jurisdiction in setting aside the arbitral award impugned before it.
11. For convenience, we shall deal with the impugned judgment
and order passed by the High Court claim-wise. The first claim is with
respect to "price adjustment/escalation"; the second claim is with respect
to "fixed costs" and the third claim is with respect to "escrow account".
11.1 Now so far as the claim with respect to "price adjustment/
escalation" is concerned, the learned arbitrator held that the date of
commencement of the first operating year for the purposes of clauses
5.2.2 read with 5.4.3 would be 25.06.2011 and therefore zero year for
the purpose of price escalation has to be 2011-12. Accordingly, the
learned arbitrator considered the escalated price in F.Y. 2013-14 at
Rs.895/- per MT. However, according to the respondent, as the date of
commencement was changed from 25.06.2011 to 25.03.2013, the zero
year for the purpose of price escalation would be 2013-14. It is required
to be noted that it is not in dispute that price escalation is permissible
under the contract/agreement itself and there shall be price escalation
every year as per the formulae mentioned in the agreement, commencing
from the date of commencement. However, it is true that the initial date
of commencement, i.e., 25.06.2011 came to be extended to 25.03.2013
by mutual agreement. However, the same was due to force majeure as
there was a delay of 21 months in obtaining the forest clearance and
environmental clearance. The price was quoted in the year 2007-08,
applicable from 2011. However, there was a delay in obtaining the forest
clearance and environmental clearance and therefore the date of
commencement of supply came to be changed. In between there would
be hike in labour charges, transportation charges, etc. Though the date
A
B
C
D
E
F
G
H
743
of commencement of supply was extended, there was no corresponding
amendment in the relevant clauses of the agreement with respect to
price escalation. There was no specific agreement that in the year
2013, the appellant would supply the coal at the same price, without any
price escalation. Therefore, considering the overall facts and
circumstances of the case and by giving cogent reasons, the learned
arbitrator interpreted the relevant clauses of the contract and specifically
held that the date of commencement of the first operating year for the
purposes of clauses 5.2.2 read with 5.4.3 would be 25.06.2011 and
accordingly the zero year for the purpose of price escalation would be
2011-12 and therefore the appellant shall be entitled to the enhanced
amount as is applicable in the year 2013-14 (the price escalation). Having
considered the reasoning given by the learned arbitrator, we are of the
opinion that the interpretation by the learned arbitrator was both possible
as well as plausible. Therefore, merely because some other view could
have been taken, the High Court is not justified in interfering with the
interpretation made by the arbitrator which as observed was possible
and plausible. Therefore, in the facts and circumstances of the case,
we are of the opinion that the High Court has clearly exceeded in its
jurisdiction in interfering with the award passed by the learned arbitrator
with respect to claim no.1 - price adjustment/escalation. At this stage,
it is required to be noted that though the High Court has observed that
the award passed by the learned arbitrator with respect to claim no.1
was against the public policy, with respect, we do not see any element of
public policy. It was pure and simple case of interpretation of the relevant
clauses of the agreement which does not involve any public policy.
Therefore, we are of the opinion that the impugned judgment and order
passed by the High Court for quashing and setting aside the award passed
by the learned arbitrator with respect to claim no.1 - price adjustment/
escalation cannot be sustained and the same deserves to be quashed
and set aside.
11.2 Now so far as claim no.2 - "fixed costs" and an amount of
Rs.78 crores awarded by the learned arbitrator with respect to
compensation of loss is concerned, having gone through the relevant
material on record, we are of the opinion that the High Court has rightly
set aside the award passed by the learned arbitrator with respect to
claim no.2. Except the CA's certificate, no further evidence had been
led with respect to actual loss. Considering the material on record, it is
PARSA KENTE COLLIERIES LTD. v. RAJASTHAN RAJYA
VIDYUT UTPADAN NIGAM LTD. [M. R. SHAH, J.]
A
B
C
D
E
F
G
H
744
SUPREME COURT REPORTS
[2019] 8 S.C.R.
on the contrary found that in the relevant year the quantity of the coal
lifted by the respondent was much above the fixed quantity.