# STEEL AUTHORITY OF INDIA LTD v. J.C. BUDHARAJA, GOVERNMENT AND MINING CONTRACTOR

- **Citation:** [1999] Supp. 2 S.C.R. 155
- **Court:** Supreme Court of India
- **Decided:** 1999-09-01
- **Case number:** Civil Appeal No. 507 of 1992
- **Bench:** D.P. Wadhwa, M.B. Shah
- **Source:** https://unisonlegal.in/judgment/supreme-court-of-india/steel-authority-of-india-ltd-v-j-c-budharaja-government-and-mining-contractor-16806
- **Pages:** 19

## Headnote

B
Arbitration Act, 1940: Section 30.
Misconduct-Jurisdictional error-Contract stipulated that no claim
would be tenable for delay in handing over the work site-Contract only C
provided extension of time for completion in case of such delay-Despite
such prohibition, award given for losses due to delay in handing over work
site-Held: Arbitrator has to function within the limits of the agreement and
cannot exceed his jurisdiction-Whether or not the arbitrator has so functioned
would be a jurisdictional fact and required to be gone into by the court- D
Arbitrator may have jurisdiction to entertain a claim but does not have
jurisdiction to pass award in respect 'of prohibited items of contract-I/ he
does so it will be a jurisdictional error-Hence, the said award is, on the face
of it, illegal.
Arbitration-Disputes-Reference to-Period of limitation-Cause of
action-Arising of-Contractor gave notice on 29-8-1979 demanding a E
certain sum-No response and no payment from company-Contractor's right
to receive damages not kept alive in subsequent supplementary agreementInstead contractor agreed to complete work within the stipulated time on a
higher rate-Company wrote letter in [on 3.9.1983} repudiating the claim
made by the contractor-No action to refer the dispute for arbitration taken p
by contractor within 3 years from 29-8-1979-When dispute with regard to
second agreement [dated 20.12.1980} arose in 1985 contractor gave notice
for appointment of arbitrator and the matter was referred to arbitration-In
that reference contractor raised the dispute pertaining to the first agreementArbitrator appointed in December I 985 with reservation that the claim was
barred by the period of limitation-Held: Cause of action arose on G
29-8-1979, the date of notice of demand-Hence, Claim before the arbitrator
in December 1985 barred by period of limitation-:-Letter written in 1983
would not give fresh cause of action because on that date cause of action
for recovering the amount was barred by the period of three years prescribed
under Art. 137 of the Limitation Act-Under S. 3 of the Limitation Act it was H
155
'\
Cl
156
SUPREME COURT REPORTS [1999] SUPP. 2 S.C.R.
A the duty of the arbitrator to reject the claim as it was, on the face of it, barred
by limitation-Limitation Act, 1963, Art. 13 7 and S. 3.
Arbitration-4ward-Speaking or non-speaking-Contractor claimed
damages for delay in handing over the work site-Arbitrator awarded damages
and also gave reasons for it-Held: The reasons clearly reveal that the
B award is a speaking award-Hence, court can go behind it.
The predecessor of the appellant executed a contract with the
predecessor of the respondent for certain construction within a wild life
sanctuary. The agreement stipulated that no claim for delay in giving the
C entire site or giving it gradually would be tenable and in such cases the
appellant was only obliged to extend the time for completion of the work.
The respondent raised a dispute on 29-8-1979 for losses incurred due
to delay in handing over the work site but there was no response from the
appellant and no payment was made. Thereafter a supplementary agreement
D was executed between the appellant and the respondent in which it was
nowhere stated that the respondent's .alleged right of getting payment for
damages or losses suffered was kept alive. On the contrary, the respondent
had agreed to complete the work within the time stipulated in the second
agreement by charging some higher rate. The respondent had not sought
E any reference of the aforesaid dispute within three years from the date when
cause of action arose i.e., 29-8-1979. However, the appellant wrote a letter
in 1983 repudiating the respondent's claim on account of damages or losses
suffered by him.
When a dispute arose with regard to the second agreement the
F respondent gave a notice on 2-12-1985 to appoint an arbitrator and the
matter was referred to arbitration. In that reference, the respondent raised
certain claims

## Text

_Characters 0–39,747 of 47,072. This is a partial read: ask again with offset=39747 for what follows._

STEEL AUTHORITY OF INDIA LTD.
A
v.
J.C. BUDHARAJA, GOVERNMENT AND MINING CONTRACTOR
SEPTEMBER 1, 1999
[D.P. WADHWA AND M.B. SHAH, JJ.]
B
Arbitration Act, 1940: Section 30.
Misconduct-Jurisdictional error-Contract stipulated that no claim
would be tenable for delay in handing over the work site-Contract only C
provided extension of time for completion in case of such delay-Despite
such prohibition, award given for losses due to delay in handing over work
site-Held: Arbitrator has to function within the limits of the agreement and
cannot exceed his jurisdiction-Whether or not the arbitrator has so functioned
would be a jurisdictional fact and required to be gone into by the court- D
Arbitrator may have jurisdiction to entertain a claim but does not have
jurisdiction to pass award in respect 'of prohibited items of contract-I/ he
does so it will be a jurisdictional error-Hence, the said award is, on the face
of it, illegal.
Arbitration-Disputes-Reference to-Period of limitation-Cause of
action-Arising of-Contractor gave notice on 29-8-1979 demanding a E
certain sum-No response and no payment from company-Contractor's right
to receive damages not kept alive in subsequent supplementary agreementInstead contractor agreed to complete work within the stipulated time on a
higher rate-Company wrote letter in [on 3.9.1983} repudiating the claim
made by the contractor-No action to refer the dispute for arbitration taken p
by contractor within 3 years from 29-8-1979-When dispute with regard to
second agreement [dated 20.12.1980} arose in 1985 contractor gave notice
for appointment of arbitrator and the matter was referred to arbitration-In
that reference contractor raised the dispute pertaining to the first agreementArbitrator appointed in December I 985 with reservation that the claim was
barred by the period of limitation-Held: Cause of action arose on G
29-8-1979, the date of notice of demand-Hence, Claim before the arbitrator
in December 1985 barred by period of limitation-:-Letter written in 1983
would not give fresh cause of action because on that date cause of action
for recovering the amount was barred by the period of three years prescribed
under Art. 137 of the Limitation Act-Under S. 3 of the Limitation Act it was H
155
'\
Cl
156
SUPREME COURT REPORTS [1999] SUPP. 2 S.C.R.
A the duty of the arbitrator to reject the claim as it was, on the face of it, barred
by limitation-Limitation Act, 1963, Art. 13 7 and S. 3.
Arbitration-4ward-Speaking or non-speaking-Contractor claimed
damages for delay in handing over the work site-Arbitrator awarded damages
and also gave reasons for it-Held: The reasons clearly reveal that the
B award is a speaking award-Hence, court can go behind it.
The predecessor of the appellant executed a contract with the
predecessor of the respondent for certain construction within a wild life
sanctuary. The agreement stipulated that no claim for delay in giving the
C entire site or giving it gradually would be tenable and in such cases the
appellant was only obliged to extend the time for completion of the work.
The respondent raised a dispute on 29-8-1979 for losses incurred due
to delay in handing over the work site but there was no response from the
appellant and no payment was made. Thereafter a supplementary agreement
D was executed between the appellant and the respondent in which it was
nowhere stated that the respondent's .alleged right of getting payment for
damages or losses suffered was kept alive. On the contrary, the respondent
had agreed to complete the work within the time stipulated in the second
agreement by charging some higher rate. The respondent had not sought
E any reference of the aforesaid dispute within three years from the date when
cause of action arose i.e., 29-8-1979. However, the appellant wrote a letter
in 1983 repudiating the respondent's claim on account of damages or losses
suffered by him.
When a dispute arose with regard to the second agreement the
F respondent gave a notice on 2-12-1985 to appoint an arbitrator and the
matter was referred to arbitration. In that reference, the respondent raised
certain claims relating to the work done under the first agreement. The
appellant appointed an arbitrator with a specific reservation regarding the
tenability, maintainability and validity of reference as also on the ground that
G the claim was barred by the period of limitation and it pertained to excepted
matters in the terms of the general conditions of the contract.
The arbitrator awarded damages for losses incurred by the respondent
"for the reasons" of delay in handing over the work site to the respondent
under the first agreement. The award was made rule of the Court and the
H appeal filed against it was dismissed by the High Court. Hence this appeal.
STEEL AUTHORITY OF INDIA LTD. v. J.C. BUDHARAJA. GOVT. AND MINING CONTRACTOR
157
On behalf of the appellant it was contended that the award passed by A
..,.
the arbitrator was without jurisdiction and that the claim made by the
respondent was barred by the period of limitation.
On behalf of the respondent it was contended that the award was nonspeaking and, therefore, the courts below rightly refused to interfere with
~
B
Allowing the appeal, the Court
HELD: 1.1. It is settled law that arbitrator derives his authority from
the contract and if he acts in manifest disregard of the contract, the award
given by him would be an arbitrary one. Further, the Arbitration Act, 1940 C
does not give any pol,Ver to the arbitrator to act arbitrarily or capriciously.
His existence depends upon the agreement and his function is to act within
the limits of the said agreement. [165-G-H; 166-B-C]
1.2. To find out whether the arbitrator has travelled beyond his
jurisdiction and acted beyond the terms of the agreement between the parties, D
the agreement is required to be looked into. It is true that interpretations
of a particular condition in the agreement would be within the jurisdiction
of the arbitrator. However, in cases where there is no question of interpretation
of any term of the contract, but of solely reading the same as it is and still
the arbitrator ignores it and awards the amount despite the prohibition in E
the agreement, the award would be arbitrary, capricious and without
jurisdiction. Whether the arbitrator has acted beyond the terms of the
contract or has travelled beyond his jurisdiction would depend upon facts,
which however would be jurisdictional facts, and are required to be gone into
by the court. Arbitrator may have jurisdiction to entertain the claim and yet
he may not have jurisdiction to pass award for particular items in view of F
the prohibition contained in the contract and, in such cases, it would be a
jurisdictional error. For this limited purpose reference to the terms of the
contract is a must. [166-F-H; 167-A)
Continental Construction Co. Ltd. v. State of MP., [1988) 3 SCC 82;
New Indi~ Civil Erectors (P) Ltd. v. Oil and Natural Gas. Corporation, G
(1997) 11 SCC 75; H.P. State Electricity Board v. R.J. Shah and Company,
[1994) 4 SCC 214 and Associated Engineering Co. v. Government of A.P.,
[1991) 4 sec 93, relied on.
1.3. In the instant case, the award passed by the arbitrator is against
the conditions agreed by the contacting parties and is in conscious disregard H
158
SUPREME COURT REPORTS (1999] SUPP. 2 S.C.R.
A of stipulations of the contract from which the arbitrator derives his authority.
His appointment as a sole arbitrator itself was a conditional one. Despite this
he has ignored the stipulations and conditions between the parties. Hence,
the said award is, on the face of it, illegal. [168-G-H; 169-A-B)
2. Right to refer the dispute to the arbitrator arose in 1979 when the
B contractor gave a notice demanding t~e amount and there was no response
from the appellant and the amount was not paid. The cause of action for
recovery of the said amount arose from the date of the notice. The contractor
cannot wait indefinitely and is required to take action within the period of
limitation. Hence, the cl.aim before the arbitrator in December 1985 was
C barred by the period of limitation. Letter written in 1983 by the appellant
repudiating the respondent's claim on account of damages or losses sustained
by him would not give a fresh cause of action. On that date cause of action
for recovering the said amount was barred by the period of three years
prescribed under Article 137 of the Limitation Act, 1963. Under Section 3
of the Limitation Act, it was the duty of the arbitrator to reject the claim as
D it was, on the face of it, barred by the period of limitation.
E
(171-G-H; 173-C-D]
State ofOrissa v. Damodar Das, (1996) 2 SCC 216 and Panchu Gopal
Bose v. Board of Trustees for the Port of Calcutta, (1993) 4 SCC 338, relied
on.
Major (Retd) Inder Singh Rekhi v. Delhi Development Authority, [1988)
2 sec 338, referred to.
3. The reasons, which are specifically mentioned in the award for
granting damages, clearly reveal that the arbitrator has passed a speaking
F award. Hence the Court could go behind it.
CIVIL APPELLATE JURISDICTION: Civil Appeal No. 507 of
1992.
From the Judgment and Order dated 11.9.91 of the Patna High Court in
G M.A. NQ. 621 of 1990.
Dhruv Mehta and M.P. Vinod for the Appellant.
G.L. Sanghi and Raj Kumar Mahta for the Respondent.
H
The Judgment of the Court was delivered by
I
STEEL AUTHORITY OF INDIA LTD. v. JC. BUDHARAJA, GOVT. AND MINING CONTRACTOR [SHAH, J.] 159
SHAH, J. This appeal is filed against the judgment and order dated A
11th September, 1991 passed by the Patna High Court, Ranchi Bench in
Miscellaneous Appeal No.621of1990 under Section 39(1)(vi) of the Arbitration
Act, 1940 (hereinafter referred to as "the Act"). The High Court dismissed the
appeal filed by the appellant and confirmed the order dated 2nd April, I 990
passed by the Subordinate Judge, 1st Court, Chas in Arbitration Suit No. 28 B
of 1988 by which award is made rule of Court with 8 per cent per annum
interest from the date of the decree.
It is undisputed that the National Mineral Development Corporation,
predecessor of the Steel Authority of India Limited on l .8.1977 executed a
contract with the respondent for construction of tailing-cum-storage reservoir C
at Kundi for Megha Taburu Iron Ore Project. As per the terms of the contract,
the work was to be completed within a period of two years. During this period,
Public Sector Iron and Steel Companies (Re-structuring and Miscellaneous
Provisions) Act, 1978 was passed and Steel Authority of India Limited became
the employer in place of National Mineral Development Corporation. Further,
the contractor, N.C. Budharaja also died and was succeeded by the present D
respondent.
After two years of contract period, on 29th August, 1979, respondent
raised the claim of about 18 lakhs as damages for delay in handing over work
sites and allied reasons. On 20th December, 1980, a supplementary agreement
was executed between the appellant and the respondent for the same work E
at an increased rate. The relevant part of the said agreement is as under:
"The Supplementary agreement made this twentieth day of December,
1980 between Steel Authority of India Limited having its registered
office at Hindustan Times House, 18/20, Kasturba Gandhi Marg, New F
Delhi -
l l 0 00 l and having one of its units at Bokaro Steel Plant at
Bokaro Steel City (hereinafter referred to as the (Employer) which
expression shall include its successors and assigns) of the one part
and Mis N.C. Budharaja Govt. and Mining Contractor, at Jharpada,
P.O. Budheswari Colony, Bhubaneswar (hereinafter referred to as the
"Contractor") which expression shall include its successors and assigns G .
of the other part.
WHEREAS the contractor entered into an agreement dt. lst August
1977 with Mis National Mineral Development Corporation Limited in
regard to the work of "Constructions of Tailing-cum-Storage Reservoir"
at Meghahatuburu Iron Ore Project relating to their Meghahatuburu H
160
SUPREME COURT REPORTS [1999] SUPP. 2 S.C.R.
.
'
A
Iron Ore Project.
B
c
D
E
F
AND-,WHEREAS the-said--unit of the National Mineral
Development Corporation Limited after the coming into force of the
Public Sector Iron and Steel Companies (Restructuring and
Miscellaneous Provisions) Act, 1978 was transferred to Steel Authority
of India Limited and declared as a captive unit for the Bokaro Steel
Plant of Steel Authority of India Limited.
AND WHEREAS pursuant to the provisions of Section 23 of the
Restructuring Act aforesaid, the agreement entered into by and between
Mis National Mineral Development Corporation Ltd. in respect of
Meghahatuburu unit of Mis National Mineral Development Authority
Ltd. became fully enforceable and effective against or in favour of
Steel Authority of India Limited.
AND WHEREAS the Contractor is yet to execute a considerable
portion of the work more particularly described in the schedule to this
agreement.
AND WHEREAS the contractor has agreed to complete the said
balance work as on 12.3.80 the estimated quantity of which is set out .·
in document specified at 2(d) on the terms and conditions hereinafter
enumerated."
Further clauses 3 and 4 of the said agreement read as under:
"3. In consideration of the payments to be made by the employer to
the Contractor as hereinafter mentioned the contractor hereby
covenants with the employer to construct, complete and maintain the
works in conformity with the provisions of contract in all respect.
4. The employer hereby covenants to pay to the contractor in
consideration of the construction, completion ancl maintenance of the
works the contract price at the time and in the manner prescribed by
G
the contract."
Despite the aforesaid fact that the supplementary agreement was
executed for the same work at an increased rate, it is stated that the appellant
wrote letter dated 3.9.1983 repudiating claim of 18 lakhs on account of damages
for any loss sustained by the contractor as claimed by him by his letter dated
H 29th August, l 979.
/
l
STEEL AUTHORITY OF rNDIA LTD. 1·. J.C. l!UDHARAJA, GOVT. AND MINING CONTRACTOR (SHAH. J ]
161
Thereafter, dispute arose in the year 1985 for the work with regard to A
·. second agreement dated 20th December, 1980 and the matter \:Vas referred to
arbitration. In that Reference, respondent raised certain claims relating to the
work done under the first agreement. On 2{ld December, 1985, the appellant
raised an objection that the claim could not be decided by the Arbitrators as
the s!)me was pertaining to previous agreement. Thereafter respondent gave B
notice dated 2nd December, 1985 to the appellant to appoint sole arbitrator
as provided for under the first agreement. On 10th December, 1985, the
appellant appointed sole arbitrator "with reservation regarding the tenability,
maintainability and validity of the Reference as also on further grounds that
the claim was barred by the period of limitation and that it pertained to
excepted matters of general conditions of the contract".
On 11th July, 1986, the arbitrators gave an award pertaining to the
dispute under the agreement dated 20.12.1980. Against the claim of Item No. l
of Rs.17 lakhs and odd pertaining to first agreement, the arbitrators awarded
'Nil'; this award has been made rule of the Court by the High Court of Delhi.
Meanwhile, the appellant challenged the jurisdiction of the sole arbitrator
by filing Miscellaneous Case No. 22 of 1987. Finally, the High Court dismissed
c
D
the Revision Application on 22nd August, 1988. Thereafter on 18th November,
1988, the sole arbitr~tor made an award granting damages to the tune of
Rs.11,26,296 as principal sum (unliquidated damages) and a further sum of
Rs.12,06,000 as interest on the above principal amount from 29th August, 1979 E
till the date of the Reference, i.e., 15th December, 1985. The arbitrator also
awarded future interest at the rate of 17 per cent from the date of the award
to the date of payment or the date of decree whichever is earlier. s/ order
dated 2nd April, 1990, the learned Sub-Judge made the award rule of the court
with a modification for the payment of interest from the date of the decree F
at the rate of 8 per cent on the principal t:tmount or unpaid part till the date
of actual payment. The appeal filed before the High Court against the said
judgment and decree was also dismissed. Hence this appeal.
At the time of hearing, the learned counsel for the appellant submitted
that the award passed by the arbitrator is
G
(a)
without jurisdiction,
(b) The claim made by the respondent was on the face of it barred
by the period of limitation, and
(c)
Award of interest is wholly unjustified and illegal.
H
162
SUPREME COURT REPORTS [1999) SUPP. 2 S.C.R.
A
The learned counsel for the respondent supported the order passed by
B
the High Court. He submitted that:
(I)
The award is non-speaking. Hence, courts below rightly refused
to interfere with.
(2)
The question, whether claim made by the contractor was within
period of limitation or not, was required to be decided by the
arbitrator, and
(3)
There is no prohibition for awarding interest from the date of the
claim till the date of reference and thereafter.
C
For deciding the controversy, it would be necessary to refer to the
D
E
material part of the award dated 18th November, 1988 which is as under:
"The claimant has put forth a claim amounting to Rs.18,10,014.48
plus interest on the same amount at 30 per cent per annum from
29.8.79 till date of payment.
The amount of interest at the above rate on the claim amount from
29.8.79 till l 8.l l.88, i.e., date of"A WARD" worked out to Rs.33,39,351.00
(Rupees Thirty three lakhs thirty nine thousand three hundred fifty
one only).
Thus the total amount of claims including interest up to the ·date
of "A WARD" works out to Rs.5 l ,49,365.48 (Rupees fifty one Iakhs
forty nine thousand three hundred sixty five and paise forty eight
only).
On perusal of all documents filed by both parties and relied upon
F ·
by the parties and keeping in view oral and written submissions and
chain of arguments of both parties relating to factual and legal, I am
convinced that the claimant sustained losses on account of the
following reasons:-
(a)
The work site is located in the wild-life sanctuary of Saranda
G
Reserve forest. The project authorities issued work .order without
completing the departmental formalities in obtaining permission
of the Forest Department for executing the work inside wild-life
sanctuary.
(b) The project authorities could not obtain permission of Forest
H
Department to take men and machinery to the work site as and
...
STEEL AUTHORITY OF INDIA LTD. v. J.C. BUDHARAJA, GOVT. AND MINING CONTRACTOR [SHAH, J.)
163
when necessary for executing the work.
A
(c)
The project authorities could not obtain permission of Forest
Department in time for making hutments at work site and could
not hand over the ~ite in time.
(d) The project authority could not remove forest growths from the
working area before issue of work order.
B
(e)
The project authorities could not obtain permission of Forest
Department for transporting the required machinery and materials
for blasting operation and executing drilling and blasting work
inside the wild-life sanctuary till March 1979.
(f)
Delay in payment of legitimate dues of the claimant for more
than nine years.
c
After recording the aforesaid reasons; the arbitrator held that in
consideration of the documents, submissions and arguments of both the
parties, contractor was entitled to be paid by the Steel Authority of India D
Limited a sum ofRs.l l,26,296 as principal amount and a sum ofRs.12,06,000
as interest from 29th August, 1979 till 15th August, 1985, in all Rs.23,32,296.
The Arbitrator also awarded future interest at the rate of 17 per cent on the
principal sum of Rs.11,26,296 from the date of award till the date of payment
or the date of decree whichever is earlier .
Learned counsel for the appellant submitted that the award is a speaking
one and the Arbitrator has awarded the damages for the reasons that
department failed to obtain various permissions from the forest depai:tJnent.
E
The reasons which are specifically mentioned in the award for grantirig aamages
clearly reveal that the arbitrator has passed a speaking award. He pointed out p
the terms of the contract and submitted that it is apparent that arbitrator has
awarded the amount for the items for which there is prohibition in the contract
and thereby he has travelled beyond his jurisdiction. For this purpose, learned
counsel for the appellant referred to conditions which are referred to by the
learned Single Judge and the trial court. They are as under:
"Clause 25: No claim if work is abandoned or postponedThe successful tenderer shall have no claim whatsoever against
G
the Corporation if the work or any part thereof covered by these
tender documents if postponed to any later date or abandoned in the
overall interest of the Corporation or for any other reason. The H
164
A
B
c
SUPREME COURT REPORTS [1999] SUPP. 2 S.C.R.
Corporation's decision in the matter shall be final and binding on the
contractor.
Clause 32: Site for execution of work:
Site for execution of work will be available as soon as the work
is awarded. In case it is not possible for the Corporation to make the
entire site available on the award of work the contractor will have to
arrarrge his working programme.accordingly. No claim whatsoever for
not giving the entire site on award of work and for giving the site
gradually will be tenable.
Clause 39: (Force majeruo):
No failure or omission to carry out the provisions of the contract
shall give rise to any claim by the Corporation and the contractor,
one against the other, if such fa,ilure ommission arises from an act of
God, which shall include natural calamities such as fire, t:Jood,
D
earthquake, hurricane or any postilence, or from civil strike, compliance
with any statute or regulation of Government, lockouts and strikes,
or from any political or other reasons beyond the control or either
the Corporation or the Contractor, including war whether declared
or not, Civil war or state of insurrection.
E
F
G
Clause 5 (iv): General Conditions of Contract (Time for Completion
of work covered by the Contract):
Failure or delay by the Corporation to hand over to the contractor
possession of the lands necessary fo_r the execution of the work, or·
to give the necessary drawings instructions or any other .delay by the
Corporation which due to any other cause whatsoever shall in no way
affect or vitiate the contract or alter the character thereof or entitle the
contractor to damage or compensation therefor provided that the
Corporation may extend the time for completion of the work by such
period as it may consider necessary and proper.
Before the learned Sub-Judge and the High Court, it was submitted that
in view of the aforesaid conditions which are laid down in the contract which
prohibited award of damages or compensation, it was not open to the arbitrator
to award damages for the alleged losses sustained on account of not obtaining
or delay in obtaining various permissions required to be taken under the law
H or rules from the Forest Department.
--
..
-
...
-
...
--
STEEL AUTHORITY OF INDIA LTD. v. J.C. BUDHARAJA, GOVT. AND MINING CONTRACTOR [SHAH, J.] 165
Re: Lack of Jurisdiction of the Arbitrator
A
From the Award quoted above, it is apparent that damages are granted
by the arbitrator for delay in obtaining pennission from the Forest Department:
(a)
for executing the work inside the wildlife sanctuary;
(b) to take man and machinery to the worksite in the forest;
(c)
for making hutments at the work site and failure to hand over
site in time;
(d) failure to remove Forests growths from working area before
issue of work order; and
(e)
for transporting the required machinery and materials for blasting
operation and executing the drilling and blasting work inside the
wild-life sanctuary till March, 1979.
B
c
Clause 32 of the agreement specifically stipulates that no claim
whatsoever for not giving the entire site on award of work and for giving the D
site gradually will be tenable and the contractor is required to arrange his
working programme accordingly. Clause 39 further stipulates that no failure
or omission to carry out the provisions of the contract shall give rise to any
claim by the Corporation and the contractor, one against the other, if such
failure or omission arises from compliance with any statute or regulation of E
Government or other reasons beyond the control of either the Corporation or
the Contractor. Obtaining permission from Forest Department to carry out the
work in wild life sanctuary depends on statutory regulations. Clause (vi) of
General condition of the contract also provides that failure or delay by the
Corporation to hand over to the Contractor possession of the lands necessary
for the execution of the work or any other delay by the Corporation which F
due to any other cause whatsoever would not entitle the ~ontractor to damage
or compensation thereof; in such cases, the only duty of the Corporation was
to extend the time for completion of the work by such period as it may think
necessary and proper. These conditions specifically prohibit granting claim
for damages for the breaches mentioned therein. It was not open to the G
arbitrator to ignore the said conditions which are binding on the contracting
parties. By ignoring the same, he has acted beyond the jurisdiction conferred
upon him. It is settled law that arbitrator derives the authority from the
contract and if he acts in manifest disregard of the contract, the award given
by him would be arbitrary one. This deliberate departure from the contract
amounts not only to manifest disregard of the authority or misconduct on his H
166
SUPREME COURT REPORTS [1999) SUPP. 2 S.C.R .
. A part, but it may tantamount to mala fide action. In the present case, it is
apparent that awarding of damages of Rs. 11 lakhs and more for the alleged
lapses or delay in handing over work site is, on the face of it, against the
terms of the contract.
Further, the Arbitration Act does not give any power to the arbitrator
B to act arbitrarily or capriciously. His existence depends upon the agreement
and his function is to act within the limits of the said agreement. In Continental
Construction Co. Ltd. v. State of Madhya Pradesh, [1988] 3 SCC 82, this
Court considered the clauses of the contract which stipulated that contractor
had to complete the work in spite of rise in the prices of materials and also
C rise in labour charges at the rates stipulated in the contract. Despite this, the
arbitrator partly allowed contractor's claim. That was set aside by the Court
and the appeal filed against that was dismissed by this Court by holding that
it was not open to the contractor to claim extra costs towards rise .in prices
of material and labour and that arbitrator misconducted himself in not deciding
the specific objection regarding the legality of extra claim. In that case, the
D Court referred to the various decisions and succinctly observed:
E
"If no specific question of law is referred, the decision of the arbitrator
on that question is not final however much it may be within his
jurisdiction and indeed essential for him to decide the question
incidentally. The arbitrator is not a conciliator and cannot ignore the
Jaw or misapply it in order to do what he thinks is just and reasonable.
The arbitrator is a tribunal selected by the parties to decide their
disputes according to law and so is bound to follow and apply the
law, and if he does not he can be set right by the court provided his
error appears on the face of the award."
F
It is to be reiterated that to find out whether the arbitrator has travelled
beyond his jurisdiction and acted beyond the terms of the agreement between
the parties, agreement is required to be looked into. It is true that interpretation
of a particular condition in the agreement would be within the jurisdiction of
the arbitrator. However, in cases where there is no question of interpretation
G of any term of the contract, but of solely reading the same as it is and still
the arbitrator ignores it and awards the amount despite the _prohibition in the
agreement, the award would be arbitrary, capricious and without jurisdiction.
Whether the arbitrator has acted beyond the. terms of the contract or has
travelled beyond his jurisdiction would depend upon facts, which however
would be jurisdictional facts, and are required .to be gone into by the court.
H Arbitrator may have jurisdiction to entertain claim and yet he may not have
..--
-
STEEL AU1110RITY OF INDIA LTD. v. J.C. BUDHARAJA, GOVT. AND MINING CONTRACTOR (SHAH, J.) 167
jurisdiction to pass award for particular items in view of the prohibition A
contained in the contract and, in such cases, it would be a jurisdictional error.
For this limited purpose reference to the terms of the contract is a must.
Dealing with similar question this Court in New India Civil Erectors (P) Ltd.
v. Oil and Natural Gas Corporation, [1997) 11 SCC 75 held thus:
"It is axiomatic .that the arbitrator being a creature of the agreement, B
must operate within the four comers of the agreement and cannot
travel beyond it. More particularly, he cannot award any amount
which is ruled out or prohibited by the terms of the agreement. In this
case, the agreement between the parties clearly says that in measuring
the built-up area, the balcony areas should be excluded. The arbitrators C
could not have acted contrary to the said stipulation and awarded any
amount to the appellant on that account".
However, the learned Counsel for the Respondent submitted that the
award being non-speaking one, the learned Sub-Judge and the High Court
have rightly refused to go behind the award or interfere with. In our view, this D
submission is without any substance. It is apparent that the Arbitrator has
awarded Rs. 11,26,296 for the losses sustained for the reasons stated therein
which we have incorporated in the previous paragraph. These reasons only
pertained to non-obtaining or delay in obtaining permission from the Forest
Department as the work site was located in the wild-life sanctuary of Saranda
reserve forest. The Arbitrator in his award in terms mentioned "/am convinced E
that the claimant sustained losses on account of following reasons" and
thereafter reasons are recorded. Therefore, it cannot be said that the award
is a non-speaking one.
Further even if such reasons are not recorded, the claim itself for such
prohibited items was not entertainable by the Arbitrator. In the agreement F
between the parties, there is specific bar to raising of such claims. Hence the
decision of the arbitrator is without jurisdiction. This·aspect is also dealt with
by this Court in H.P. State Electricity Board v. J{J. Shah and Company,
[ 1999] 4 SCC 214. In paragraph 26, the Court held as under:
"In order to determine whether the arbitrator has acted irr excess of
jurisdiction what has to be seen is whether the claimant could raise
a particular dispute or claim before the arbitrator. If the answer is in
affirmative, then it is clear that arbitrator would have the jurisdiction
to deal with such a claim. On the other hand if the arbitration clause
G
or a specific term in the contract or the law does not permit or give H
168
SUPREME COURT REPORTS [1999) SUPP. 2 S.C.R.
. · A
the arbitrator the power to decide or to adjudicate on a dispute raised
by the claimant or there is a specific bar to the raising of a particular
dispute or claim, then any decision given by the Arbitrator in respect
thereof would clearly be in excess of jurisdiction."
The Court further held that in order 'to find out whether the Arbitrator
B has acted in excess of the jurisdiction, the Court may have to look into some
documents including the contract as well as the reference of the dispute made
to the Arbitrator limited for ~e purpose of seeing whether the Arbitrator has
the jurisdiction to decide the claim made in the arbitration preceedings.
Further dealing with the similar condition in the contract, such as no
C claim for price escalation other than those provided therein shall be entertained
and "the Contractor will not be entitled for any extra rate due to change in
sel~ction of querries", this Court in Associated Engineering Co. v. Government
of Andhra Pradesh and Anr., [1991] 4 SCC 93, observed that four claims
mentioned therein. were not payable under the contract, in fact, it prohibited
D such payment and for this purpose. The Court held "this conclusion is
reached not by construction of the contract but by merely looking at the
contract". The Court further observed that the Arbitrator could not act
arbitrarily, irrationally, capriciously or independently of the contract; his sole
fiJnction is to arbitrate in terms of the contract. The Court further held thus:
E
F
G
"An arbitrator who acts in manifest disregard of the contract acts
without jurisdiction. His authority is derived from the contract and is
governed by the Arbitration Act which embodies principles derived
from a specialised branch of the law of agency (see Mustill and
Boyd's Commercial Arbitration, 2nd edn., p. 641 ). He commits
misconduct if by his award he decides matters excluded by the
agreement (see Halsbury's Laws of England, Volume II, 4th edn., para
622). A delibera~e departure from contract amounts to not only manifest
disregard of his authority or a misconduct· on his part, but it may
tantamount to a' mala fide action. A conscious disregard of the law or
the provisions of the contract from which he has derived his authority
vitiates the award."
In view of the aforesaid settled law, the award passed by the arbitrator
is against the conditions agreed by the contracting parties and is in conscious
disregard of stipulations of the contract from which the arbitrator derives his
authority. His appointment as a sole arbitrator itself was conditional one and
H he was informed that the same was "with reservation regarding the tenability,
STEEL AUTHORITY OF INDIA LTD. v. J.C. BUDHARAJA, GOVT. AND MINING CONTRACTOR[SHAH, J.) 169
maintainability and validity of the Reference as also on further grounds that A
the claim was barred by the period of limitation and that it pertained to
excepted matters of general conditions of the contract". Despite this he has
ignored the stipulations and conditions between parties. Hence, the said
award is, on the face of it, illegal.
Re: LIMITATION
Our next question is of limitation. The period of limitation is required
to be considered on the basis of the arbitration clause between the parties
which is as under:
B
c
"All disputes or differences whatsoever which shall at any time arise
between the parties hereto touching or concerning the works or the execution
meaning operation or effect thereof or to the rights or liabilities of parties or
arising out of or in relation thereto, whether during or after completion of the
contract, or whether before or after determination, foreclosure or breach of the
contract (other that those in respect of which the decision of any person is · D
by the contract expressed to be final and binding) shall after written notice
by either party to the contract to the other of them and to the M.D./Chairman
of the Corporation (who will be the appointing Authority) be referred for
adjudication to be sole Arbitrator to be appointed as hereafter. provided.
The Appointing Authority will send within thirty days of the receipt of
notice a panel of three names of persons not directly connected with the work
of the contractor who will select any one of the persons named to be appointed
E
as a sole Arbitrator within thirty days of receipt of the names. If the Contractor
fails to select the name from the panel and communicate within 30 days, the
appointing authority shall appoint one out of the panel as sole Arbitrator.
F
If the Appointing Authority fails to send to the contn~ctor the panel of
three names, as aforesaid, within the period specified, the Contractor shall
send to the Appointing Authority a panel of three names of persons who
shall all be unconnected with the organisation by which the work is executed. G
The Appointing Authority shall on receipt of the names as aforesaid select
any one of the persons named and appoint him as the Sole Arbitrator, if the
appointing authority fails to select the person and appoint him as the Sole
Arbitrator within 30 days of receipt of the panel and inform the contractor
accordingly, the Contractor shall be entitled to invoke the provisions of the
Indian Arbitration Act, 1940 and any statutory modification thereof."
H
170
SUPREME COURT REPORTS [1999],SUPP. 2 S.C.R.
A
In view of the aforesaid arbitration clause, even though the claim made
by the contractor was time barred, the dispute was required to be referred to
the arbitrator. However, the reference was subject to the condition that it was
barred by the period of limitation. In that context, the learned counsel for the
appellant submitted that it is settled law that application under Section 20 or
notice for appointment of arbitrator is to be filed within three years from the
B date when 'cause of action' arises as provided in Article 137 of the Limitation
Act, 1963. The application filed by the contractor in December 1985 was, on
the face of it, time barred because the cause of action to recover the amount
arose, according to the contractor, in August 1979 when he demanded the
alleged damages for loss suffered by him because of the delay in handing
C over the worksites. He further submitted that, in the present case, in year 1980
for the same work, the Contractor has executed a supplementary agreement
for the completion of the work within the stipulated time and at a higher rate.
This would also show that Contractor waived his alleged right of asking for
appointment of Arbitrator as provided in arbitration clause. He referred to the
arbitration clause and pointed out that within 30 days of the receipt of the
D notice, arbitrator is required to be appointed by the Managing Director. If
arbitrator is not appointed· then Contractor has option to send the panel of
three names from which arbitrator is required to be appointed. He contended
that after the supplementary agreement, there was no question of adjudicating
the so- called demand made by the contractor in the year 1979. In any case,
E he submitted that the Contractor ought to have approached the Court under
Section 20 or ought to have demanded arbitration within three years from the
date of the notice demanding the amount for loss suffered by him. As against
this, learned Counsel for the respondent submitted that the cause of action
to refer the matter to the arbitrator arose only in 1983 when respondent denied
contractors' claim.
F
For deciding this controversy, we would first refer to the decision of
this Court in the State o/Orissa & Ors. v. Damodar Das, [1996] 2 SCC 216
wherein this Court held that Section 3 of the Limitation Act, 1963, enjoys the
power to consider the question of limitation whether it is pleaded or not. The
G Court in paragraph 5 held as under:
"Russell on Arbitration by Anthony Walton (19th Edn.) at pp. 4-5
states that the period of limitation for commencing an arbitration runs
from the date on which the "cause of arbitration" accrued, that is to
say, from the date when the claimant first acquired either a right of
H
action or a right to require an arbitration take place upon the dispute
.
~.
<
•
STEEL AUTHORITY OF INDIA LTD. v. J.C. BUDHARAJA, GOVT. AND MINING CONTRACTOR [SHAH, J.] 171
concerned.